HomeMy WebLinkAboutC-2293A
TITLE(S) :
This page is part of your document - DO NOT DISCARD
�. 20071381303 Pages:
i • W�,. 0651,
Recorded /Filed in Official Records
Recorder's Office, Los Angeles County, Fee: 0.00
California Tax: 0.00
06/07/07 AT 08:07AM Other: 0.00
Total: 0.00
I
768781 200706070010035 Mail
i
Assessor's Identification Number (AIN)
To be completed by Examiner OR Title Company in black ink.
—
-F - - - .
Number of AIN's Shown
® WHO THIS FORM IS NOT TO BE DUPLICATED
EXEMPT FROM RECORDER'S FEES 06/07/07
Pursuant to Government Code §§ 6103 and 27383
Recording requested by and when recorded return to:
City Clerk -"'r IJ81303
City of Arcadia
240 Huntington Drive
Arcadia, CA 91066
(SPACE ABOVE FOR RECORDER'S USE)
DEVELOPMENT AGREEMENT
By and Between
THE CITY OF ARCADIA,
a California municipal corporation
and
SANTA ANITA ASSOCIATES, LLC, a Delaware limited liability company (a joint
venture between SANTA ANITA ASSOCIATES HOLDING CO., LLC, a California limited
liability company and SANTA ANITA COMMERCIAL ENTERPRISE, Inc., a Delaware
corporation ) and THE SANTA ANITA COMPANIES, INC., a California corporation
1.
2.
3.
4.
5.
91
7
8.
9.
10.
11.
12.
13.
14.
15.
16.
17.
18.
19.
20
21.
22.
23.
24.
25.
26.
27.
28.
29.
• •
TABLE OF CONTENTS
Definitions........................................................... ...............................
Binding Effect; Change in Developer Composition .............................
Negation of Agency ............................................. ...............................
Reserved Powers ................................................ ...............................
Acknowledgements, Agreements and Assurances on the Part of the
Developer............................................................ ...............................
Acknowledgements, Agreements and Assurances on the Part of the
City...................................................................... ...............................
Acknowledgements, Agreements, and Assurances on the Part of the
Parties................................................................. ...............................
PublicBenefits ...................................................... ...............................
Cooperation and Implementation ........................ ...............................
Compliance; Default; Termination; Modifications and Amendments..
Amendment or Modification ................................. ...............................
Term of Agreement ............................................. ...............................
Administration of Agreement and Resolution of Disputes ...................
Transfers and Assignments
3
Page(s)
.............4
.............7
.............7
.............7
...........10
...........10
...........15
...........16
...........16
...........18
........... 21
........... 21
............................................. ...............................
MortgageeRights ............................................................ ...............................
Notices............................................................................ ...............................
22
24
25
28
Severability....................................................................... ............................... 29
Timeof Essence ................................................................. .............................29
Force Majeure /Enforced Delay; Extension Of Time Of Performance ..............30
Waiver................................................................................ .............................30
No Third Party Beneficiaries ............................................... .............................30
EstoppelCertificates .......................................................... .............................30
Attorney's Fees ................................................................ ............................... 31
ApplicableLaw ................................................................... .............................31
Authorityto Execute ......................................................... ............................... 31
Entire Agreement; Conflicts ................................................ .............................32
City Approvals and Actions ................................................ .............................32
Counterparts..................................................................... ............................... 32
Exhibits............................................................................. ............................... 32
30. Interpretation ........................................................................ ............................... 32
31. Copies of Existing Land Use Regulations and Existing Development
Approvals......................................................................... ............................... 32
I
Development Agreement
This Development Agreement ( "Agreement ") is made in Los Angeles County,
California as of Oliy► e- 1 , 2007, by and between the City of Arcadia, a
municipal corporation and charter city (the "City"), and Santa Anita Associates, LLC, a
Delaware limited liability company ( "SAA") (a joint venture between Santa Anita
Associates Holding Co., LLC, a California limited liability company ( "Caruso ") and
Santa Anita Commercial Enterprise, Inc., a Delaware corporation ( "SACE ")) and The
Santa Anita Companies, Inc., a California corporation ( "Owner") (SAA and Owner are
sometimes collectively referred to herein as the "Developer"). The City and the
Developer shall be referred to singularly as a "Party" or collectively as the "Parties."
Recitals. This Agreement is made with respect to the following facts and for the
following purposes:
A. The City is authorized, pursuant to its authority as a charter city over
municipal affairs and pursuant to Government Code Sections 65864 - 65859.5 (the
"Development Agreement Statute "), to enter into binding agreements with persons
having a legal or equitable interest in real property located in the City for the
development of such property in order to establish certainty in the development
process, the City has adopted Resolution No. 6469 establishing policies for the
consideration of development agreements under the Development Agreement Statute,
the Parties hereto acknowledge that this Agreement has been considered and adopted
in compliance with the Development Agreement Statute and Resolution No. 6469;
B. Owner is the fee owner of an approximately 304 -acre site located in the
City, legally described in Exhibit "A" attached hereto and depicted in the diagram
attached as Exhibit "B" (the "Entire Property "). Caruso is managed by an experienced
developer of pedestrian - oriented retail centers and, as stated above, is the joint venture
partner of SACE in SAA. SAA has an option to ground lease certain land (the
"Property") pursuant to a ground lease ( "Ground Lease ") that is a part of the CE zoned
(under the Specific Plan, defined below) portion of the Entire Property. Exercise of the
option to Ground Lease is conditioned on the satisfaction or waiver of certain conditions.
SAA will develop on the Property the Commercial Entertainment Center (defined
below). The CE Zone, as depicted in the Specific Plan, is legally described in Exhibit
"A A =1" attached hereto and depicted in the diagram attached as Exhibit "B-1".
C. The City has adopted the Santa Anita Park Specific Plan through the
adoption of Ordinance No. 2226 (the "Specific Plan "), a comprehensive plan to guide
the design and future development of certain portions of the Entire Property, which has
been used historically as a horse racing facility known as the Santa Anita Racetrack.
The Specific Plan provides for the development of the Property with a new commercial
entertainment development including approximately 806,405 square feet (Gross
Leasable Area as that term is used in the Specific Plan) of retail and commercial space,
accompanying parking, as depicted in the Specific Plan, and the necessary
infrastructure to serve such uses (collectively, the "Project," defined further below), as
depicted on the site plan attached hereto as Exhibit "C" (the "Site Plan ");
0 0
D. The constituent entities of Developer have a legal or equitable interest in
their respective portions of the Entire Property in accordance with the Development
Agreement Statute. SAA desires to develop the Property with a high - quality
commercial, restaurant, entertainment and retail development project, and they require
substantial long -term planning, comprehensive design, significant investment by
Developer in public and private infrastructure, and an assurance of stable land use
entitlements in order to maximize the potential for Developer to finance and develop it.
Accordingly, consistent with the Development Agreement Statute and Resolution No.
6469, Developer has requested that City enter into this Agreement to provide certain
assurances that the Project will be permitted to proceed in accordance with, and subject
to, the provisions set forth herein and in City's Existing Land Use Regulations (defined
below), City's Existing Development Approvals (defined below), and the Future
Development Approvals (defined below) to be obtained by Developer, all as more
particularly set forth herein;
E. The City has determined that the Project is consistent with, and satisfies,
the relevant provisions of the Arcadia Municipal Code and the Specific Plan, including
the goals and objectives of the City's General Plan, as amended. City has determined
that development of the Project will provide significant benefits to the community and
that the Project promotes the public health, safety, and welfare for the following
reasons, among others:
(1) the Project ensures the comprehensive planning of a high quality
Project within the Speck Plan area that will enhance the image and stature of the City;
(2) the Project will provide a long -term source of employment
opportunities for residents of the City and the surrounding region;
(3) the Project will revitalize the Santa Anita Racetrack by incorporating
development in a manner that is complementary and respectful of the Racetrack's
important and historic role in the community;
(4) the Project will preserve historic portions of the Santa Anita
Racetrack grandstand and other historic structures by maintaining architectural
compatibility;
(5) the Project will preserve public visual accessibility of the existing
Santa Anita Racetrack grandstand such that the grandstand remains recognizable from
within the Speck Plan area and from select locations along Huntington Drive;
(6) the Project will attract new visitors to the Santa Anita Racetrack and
increase its visibility to the general public;
(7) the Project will establish a balance of land uses that benefits
various segments of the community and creates a special place that blends the design
heritage of the Santa Anita Racetrack into a new complex of uses and buildings;
I
•
(8) the Project
entertainment opportunities fo r
environment;
• 6
will offer both daytime and nighttime recreational and
the community in a safe and reasonably secure
(9) the Project will enhance the cultural fabric of the community by
providing outdoor plazas, open space areas, as well as publicly accessible art work as
articulated in the Specific Plan;
(10) the Project will provide an expanded economic base for the City
that maximizes property and sales tax revenue while balancing community design
principles;
(11) the Project will create a pedestrian- oriented open air commercial
center with an emphasis on an open space network of landscaped pedestrian streets,
sidewalks, paseos, promenades, and public space that will form an important gathering
place for the Arcadia community;
(12) the Project will ensure land use compatibility by creating a logical
physical relationship to the adjacent Westfield Santa Anita mall, existing residential
uses, and existing circulation infrastructure through vehicular and pedestrian links;
(13) the Project will develop a unique open -air commercial
entertainment center to attract retail uses;
(14) the Project will utilize architectural design, lighting, signage, and
landscape materials to give the Project a distinctive and pleasing appearance;
(15) the Project will generate public tax revenues that can be utilized to
provide police, fire, recreation and other essential and important public services to the
community; and
(16) the Project will put portions of the Entire Property to productive use
consistent with the objectives of City's General Plan.
In consideration for Developer's provision, in all material respects, of the foregoing
public benefits, City has determined that it is appropriate to enter into this Agreement to
provide assurances to Developer that the Project will be permitted to proceed in
accordance with and subject to the provisions set forth herein and in City's Existing
Land Use Regulations, City's Existing Development Approvals, and the Future
Development Approvals to be obtained by Developer, all as more particularly set forth
herein;
F. In connection with its approval of the Project, the Final Environmental
Impact Report No. SCH 2005031131 (the "Final Environmental Impact Report" or
"FEIR ") was prepared by the City and certified by the City Council on April 17, 2007.
The FOR analyzed potential adverse environmental impacts of full buildout for the
Project;
G. The City Council has found that the provisions of the Agreement are
consistent with the relevant provisions of the Arcadia Municipal Code, the City's General
Plan, as amended, and the Specific Plan;
H. All actions taken by City have been duly taken in accordance with all
applicable legal requirements, including those of the California Environmental Quality
Act, Public Resources Section 21000 at seq. ( "CEQA"), and all other requirements for
notice, public hearings, findings, votes and other procedural matters;
I. On March 19, 2007, the Planning Commission of the City of Arcadia
conducted a duly noticed public hearing concerning this Agreement, thoroughly
considered this Agreement, and recommended adoption thereof to the City Council;
J. On April 11, 2007, the City Council conducted a duly noticed public
hearing concerning this Agreement, thoroughly considered this Agreement, introduced
Ordinance No. 2228 approving this Agreement, and on May 1, 2007, the City Council
conducted a second reading of and adopted said Ordinance;
NOW, THEREFORE, in consideration of the above recitals and of the mutual
covenants and agreements contained herein and other good and valuable
consideration, the value and adequacy of which are hereby acknowledged, the Parties
agree as follows:
1. Definitions. Capitalized terms used in this Agreement shall have the
meanings set forth below, or if not defined in this Section 1, shall have the meaning
ascribed thereto when such terms are first used herein. Other initially capitalized terms
not specifically defined in this Agreement shall have the same meaning as set forth in
the Specific Plan, or, if not defined therein, in the Arcadia Municipal Code:
(a) The terms "Development," "development" and "develop"
mean the improvement of certain portions of the Entire Property for the purposes of
constructing and completing the structures, improvements and facilities comprising the
Project as more particularly described in the Specific Plan, Existing Development
Approvals, and Future Development Approvals including, but not limited to: grading; the
construction of infrastructure and public facilities related to the Project whether located
within or outside the Entire Property; the construction, demolition, reconstruction and
redevelopment of buildings and structures; and the installation of landscaping;
(b) The term "Development Approvals" means all land use,
planning, zoning and building permits and entitlements subject to approval or issuance
by City in connection with Development of the Project, including, but not limited to:
parcel maps and/or lot line adjustments; subdivisions, tentative and final maps;
conditional use permits, final development permits, architectural design reviews and
approvals; variances; parking approvals and modifications; zoning changes; specific
plan approvals or amendments; general plan approvals or amendments; substantial
:l
conformance and minor modification reviews and approvals under the Specific Plan;
grading and building permits; demolition permits; and occupancy permits for buildings;
(c) The term "Development Exaction(s)" means any requirement
or precondition of City, whether or not in connection with or pursuant to any Land Use
Regulations (defined below) or Development Approval, for the dedication of land, the
construction of public improvements or public facilities, or the payment of Development
Impact Fees;
(d) The term "Development Impact Fees" means a monetary
exaction other than a tax or special assessment, whether established for a broad class
of projects by legislation of general applicability or imposed on a specific project on an
ad hoc basis, that is charged by the City to an applicant in connection with approval of a
development project for the purpose of defraying all or a portion of the cost of public
facilities related to a development project, including, but not limited to "Quimby Act' fees
specified in Government Code section 66477 and capacity charges, as those terms are
defined in Government Code section 66013; provided however, that the tens
Development Impact Fee does not include any of the following: (1) Filing or Processing
Fees as defined herein; (2) fees or charges that are adopted and imposed by a public
agency other than the City (even if collected by the City in connection with the Project);
or (3) fees for water connections or fees for sewer connections, as those terms are
defined in Government Code section 66013.
(e) The term "Director" means the Director of the Development
Services Department of the City of Arcadia;
(f) The term "Existing Development Approvals" means all of the
Development Approvals for the Project approved or issued prior to the Effective Date of
this Agreement, and includes, without limitation, the following Development Approvals:
(1) The General Plan of the City of Arcadia, as amended by
Resolution No.6565;
(2) The Specific Plan with Design and Sign Guidelines, as
adopted by Ordinance No. 2226;
(3) Zone Change Ordinance No. 2227 for the Entire
Property;
(4) Ordinance No. 2228 approving this Agreement, and this
Agreement;
(5) The Final Environmental Impact Report, the Mitigation
Monitoring and Reporting Program adopted therefor, and the environmental findings
adopted therefor pursuant to City Council Resolution No. 6564; and
(6) Architectural Design Review for The Shops at Santa
Anita Speck Plan.
(g) The term "Existing Land Use Regulations" means all of City's
Land Use Regulations (as defined in subsection (k) below) in effect as of the Effective
Date of this Agreement, including, without limitation, the following:
No. 6565;
(1) The Arcadia General Plan, as amended by Resolution
(2) The Specific Plan, as adopted by Ordinance No. 2226;
(3) The City Charter of the City of Arcadia; and
(4) The Arcadia Municipal Code, including the Zoning Code.
(h) The term "Effective Date" means the date that Ordinance No.
2228 approving this Agreement becomes effective.
(i) The term "Filing or Processing Fees" means those fees that
are uniformly charged for all commercial projects in the City, which fees cover the
administrative costs of, among other things, reviewing and analyzing permit applications
and similar requests for ministerial and /or discretionary approvals.
(j) The term "Future Development Approvals" means
Development Approvals (other than the Existing Development Approvals), including any
amendments or modifications thereto, required or requested subsequent to the Effective
Date of this Agreement in connection with the Development of the Project and any
portion of the Entire Property.
(k) The term "Land Use Regulations" means all ordinances
(including the Specific Plan), resolutions, codes (including the Arcadia Municipal Code,
including the Zoning Code), rules, regulations and official written policies of City
governing land use development, including, without limitation: the permitted use of land;
the density or intensity of use; subdivision requirements; the maximum height and size
of proposed buildings; Development Exactions; regulations regarding the rate, time or
sequence of development; and the design standards applicable to the Development or
any portion of the Entire Property.
(I) The term "Municipal Code" means the Arcadia Municipal
Code.
(m) The term "Project" means (i) the commercial entertainment
development to be constructed on the Property consisting of up to 830,000 square feet,
calculated in accordance with the provisions of the Specific Plan (Gross Leasable Area
as that term is used in the Speck Plan), of retail and commercial space (including
offices, cinemas and restaurants), and accompanying parking as permitted by the
Specific Plan (the "Commercial Entertainment Center"), (ii) the development of the
necessary infrastructure to serve such uses, all as more particularly described in the
Specific Plan and the Existing Development Approvals, and as depicted on the attached
Site Plan.
• 0
2. Bindina Effect: Change in Developer Composition. This Agreement, and
all of the terms and conditions of this Agreement shall, to the extent permitted by law,
constitute covenants that shall run with the land comprising the applicable portions of
the Entire Property for the benefit thereof, and the benefits and burdens of this
Agreement shall be binding upon and inure to the benefit of the Parties and their
respective assigns, heirs, or other successors -in- interest. Notwithstanding any
provision of this Agreement to the contrary: (i) if prior to the expiration of the initial Term,
the Ground Lease has not been fully executed by the Owner and SAA; or (ii) in the
event that SAA is not the ground lessor under the Ground Lease prior to the grand
opening of the Project (which shall be defined for purposes of this Section as the actual,
lawful occupancy of at least fifty percent (50 %) of the square footage of the Commercial
Entertainment Center); or (iii) in the event that Caruso no longer is the manager of SAA;
or (iv) in the event that SAA does not have an equitable or leasehold interest in the
Property, then all vested rights granted under this Agreement as to the Commercial
Entertainment Center component of the Project shall terminate. In order to enable the
City to determine compliance with this Section 2, SAA, Caruso, SACE, and Owner
hereby agree to provide written certifications, provided under penalty of perjury,
necessary for the City to determine compliance or non - compliance with this Section 2.
3. Negation of Agency. The Parties acknowledge that, in entering into and
performing under this Agreement, each is acting as an independent entity and not as an
agent of the other in any respect. Nothing contained herein or in any document
executed in connection herewith shall be construed as making the City and Developer
joint venturers, partners, agents of the other, or employer /employee.
4. Reserved Powers. Notwithstanding any provisions in this Agreement to
the contrary, the City reserves the right through its Reserved Powers, as herein defined,
to enact and apply to the development of the Project on certain portions of the Entire
Property (or to deny or conditionally approve any Future Development Approval based
on) the following laws, ordinances, regulations, and written official policies after the
Effective Date (collectively, the "Reserved Powers"):
(a) Filing or Processing Fees. Adjustments to existing Filing or
Processing Fees, or new Filing or Processing Fees, by City to cover the direct,
reasonable and actual costs of processing applications for Development Approvals or
for monitoring compliance with any Development Approvals. Such Filing or Processing
Fees shall be limited to those Filing Fees or Processing Fees that are imposed on all
commercial projects within the City, and the City shall not impose any Filing or
Processing Fee on the Project merely as a result of the fact that this Development
Agreement has been entered into.
(b) Procedural Regulations. Procedural regulations relating to
hearing bodies, petitions, applications, notices, findings, records and any other matter of
procedure, applicable on a citywide basis, provided such regulations are consistent with
and impose no greater requirements, economic burdens or time delays than the
Existing Land Use Regulations, Existing Development Approvals and Future
Development Approvals.
7
lb
0 0
(c) Engineering and Construction Standards. Provisions of
building, engineering and construction standards and specifications applicable to
comparable public and private improvements set forth in the California Building
Standards Code in effect in the City at the time of the issuance of the building permit for
a building or structure shall apply to the Entire Property and the Project, including
without limitation the applicable provisions of the Uniform Building Code, Uniform
Plumbing Code, Uniform Mechanical Code, National Electrical Code, and Uniform Fire
Code.
(d) Public Health and Safetv. Regulations that City determines are
necessary because the failure of the City to adopt such regulations would place the
occupants of the applicable portion of the Entire Property, or the occupants of the City,
or both, in a condition dangerous to their health or safety, or both.
(e) Consistent Future City Ordinances. Resolutions and
Regulations. City ordinances, resolutions, regulations, and official policies governing
development and building that are in furtherance of and not in conflict with this
Agreement, the Existing Development Approvals, and the Existing Land Use
Regulations and Future Development Approvals.
(f) Consented to Ordinances. Resolutions and Regulations. Any
ordinances, resolutions, regulations, and official policies, not set forth in this Section 4,
that are in conflict with the Project, provided Developer has given written consent to the
application of such regulations to the Project.
(g) Overriding State and Federal Laws and Regulations. State and
federal laws and regulations that are adopted or approved after the Effective Date of
this Agreement that override or conflict with Developers vested rights set forth in this
Agreement ( "Overriding Laws ") shall apply to the Entire Property and/or the Project,
together with any Mandatory Implementing Regulations. For purposes of this
subparagraph (g), the term "Mandatory Implementing Regulation" shall mean any
implementing City ordinance, resolution, regulation, or written official policy that is
necessary to enable City to comply with any Overriding Law and that overrides or
conflicts with Developers vested rights set forth in this Agreement, but only if the failure
of the City to adopt and implement any such ordinance, resolution, regulation or written
official policy will result in the City losing then existing sources of revenue. Conversely,
the City shall not apply to the Project any "Optional Implementing Regulation ". The term
"Optional Implementing Regulation" shall mean any implementing City ordinance,
resolution, regulation, or written official policy that is necessary to enable City to comply
with any Overriding Law and that overrides or conflicts with Developers vested rights
set forth in this Agreement, which, if adopted, would result in the City receiving a source
of revenue that the City had not received as of the date of adoption by the City of an
Optional Implementing Regulation City may adopt any such Optional Implementing
Regulation and apply any such Optional Implementing Regulation, but the City may not
apply such Optional Implementing Regulation to the Project, or any part thereof, or to
the Entire Property, or any part thereof. Developer does not waive its right to challenge
or contest, at Developer's sole cost and expense and at no liability to the City, the
1
validity of any such Overriding Law, Mandatory Implementing Regulation or Optional
Implementing Regulation on its face or as applied to any portion of the Entire Property
and /or the Project. In the event that any such Overriding Law (and/or any Mandatory
Implementing Regulation undertaken pursuant thereto) prevents or precludes
compliance with one or more provisions of this Agreement, such provisions of this
Agreement shall be modified or suspended only as may be necessary to comply with
such Overriding Law or Mandatory Implementing Regulation and, subject to the
provisions of the following paragraph, this Agreement shall remain in full force and
effect to the extent that it is not inconsistent with such Overriding Law and its Mandatory
Implementing Regulation and that performance of the remaining provisions of this
Agreement would not be inconsistent with the intent and purposes of this Agreement.
In the event any Mandatory Implementing Regulation is being considered by the
City for adoption, City shall use good faith efforts to provide the Developer with written
notice of such fact; provided however, that nothing contained in this sentence shall
impose any monetary liability on the part of the City, its officials, officers, employees or
agents, nor shall any subsequently adopted Mandatory Implementing Regulation be
affected by the failure of the City to actually provide such notice. City and Developer
shall thereafter meet and confer in good faith concerning (i) the Overriding Law and /or
Mandatory Implementing Regulation and the City's application or application of the
same to the Entire Property, or any part thereof and /or the Project, or any part thereof,
and, (ii) modification of this Agreement, if and as necessary, to comply with such
Overriding Law and /or Mandatory Implementing Regulation. If, however, in the opinion
of Developer, the Overriding Law and/or Mandatory Implementing Regulation at issue is
inconsistent with the intent or objectives of this Agreement, or renders the remaining
provisions of this Agreement for the benefit of Developer impractical or less profitable to
enjoy and/or enforce, Developer shall have the option of either referring the matter for
resolution pursuant to the provisions of Section 13 below, or shall have the right to
terminate this Agreement upon thirty (30) days' advanced written notice to City. City
agrees to cooperate with Developer in resolving the conflict in a manner that minimizes
any financial impact upon Developer and that preserves, to the maximum feasible
extent possible, the intent and objectives of this Agreement. City shall, at City's sole
cost and expense, process Developer's proposed changes to the Project as may be
necessary to comply with such Overriding Law and /or Mandatory Implementing
Regulation and to process proposed Project changes in accordance with City
procedures and findings.
5. Acknowledgements Agreements and Assurances on the Part of the
Developer. In order to effectuate the provisions of this Agreement, and in consideration
for the City entering into this Agreement and obligating itself to carry out the covenants
and conditions set forth herein, the Developer hereby agrees and acknowledges that:
(a) Construction of the Project. Subject to the provisions of Section
7(c) below, from and after the Effective Date, each constituent entity of Developer, in
accordance with its sound business judgment, agrees to work towards development of
the portion of the Project applicable to it in accordance with the Existing Land Use
Regulations, the Existing Development Approvals, and the Future Development
1 0 0 p
Approvals to be obtained pursuant hereto. Not by way of limitation of the foregoing, in
connection with development of the Project, constituent entity of each Developer shall,
with respect to the applicable portion of the Project, subject to the provisions of this
Agreement, comply, in all material respects, with all conditions contained in the Existing
Development Approvals and all valid conditions consistent with this Agreement that City
may impose on the Future Development Approvals.
(b) Other Governmental Permits. Subject to the provisions of
Section 7(c) below, Developer shall apply in a timely manner for such other permits and
approvals as may be required from other governmental or quasi - governmental agencies
having jurisdiction over the Project for the development of, or provision of services to,
the Project. As specified in Section 6(f), City shall cooperate with Developer in its
endeavors to obtain such permits and approvals.
6. Acknowledgements Agreements ano Assurances on the ran or me %ay.
City hereby agrees that commencing on the Effective Date, and continuing during the
entire remaining Term of this Agreement, Developer shall have the vested right to carry
out and complete the Project in accordance with the express provisions of this
Agreement, the Existing Land Use Regulations, the Existing Development Approvals
and Future Development Approvals, and once the same have been obtained, the Future
Development Approvals. In furtherance of such agreement and assurance, and
pursuant to the authority and provisions set forth in the Development Agreement
Statute, City further hereby agrees and acknowledges as follows:
(a) General. The uses permitted on the applicable portions of the
Entire Property hereunder, the density and intensity of development, the maximum
height and size of buildings, and all other matters affecting land use and development of
the Project shall be as set forth in the Specific Plan, the Existing Land Use Regulations,
the Existing Development Approvals, and, once the same have been obtained, the
Future Development Approvals. In addition, subject to the City's Reserved Powers as
set forth herein, Developer's applications for Future Development Approvals shall be
reviewed pursuant to the provisions of the City's Existing Land Use Regulations and the
Existing Development Approvals.
Project. City acknowledges that Developer may in the future desire to change or modify
the precise location, configuration, size and height of the proposed buildings and
develop a mix of proposed uses after the Effective Date of this Agreement based upon
more precise planning, changes in market demand, changes in development occurring
in the vicinity, and similar factors. In such event, City shall cooperate with Developer to
review and take final action on such requested changes in accordance with City's
Existing Land Use Regulations, the Existing Development Approvals and Future
Development Approvals. No change to the Project (including Substantially Conforming
Changes under Section 7(a)) that is consistent with the Existing Land Use Regulations,
the Existing Development Approvals and Future Development Approvals shall require
an amendment of this Agreement and, in the event any change in the Project proposed
by Developer is approved by the City, the references in this Agreement to the Project or
[to]
applicable portion thereof shall be deemed to refer to the Project as so changed. In the
I'+
event that any reduction by the Developer in the scale of the Project reduces the Gross
Leasable Area of the Commercial Entertainment Center to less than Five Hundred
Thousand (500,000) square feet, all vested rights under this Agreement shall
automatically be deemed terminated. In addition, the Parties intend that if parcelization
of the Entire Property, or any portion thereof, that is consistent with the development of
the Project as contemplated under the Existing Development Approvals is, subsequent
to the Effective Date of this Agreement, authorized and approved under the Subdivision
Map Act and the Existing Land Use Regulations, no additional Development Exactions,
beyond those contemplated by this Agreement, the Existing Development Approvals,
the Existing Land Use Regulations and Future Development Approvals shall be
imposed on any such parcelization.
(c) Reservations and Dedication of Land for Public Purposes.
Developer shall not be required to dedicate, convey, or transfer any interest in land or to
construct or install public improvements or facilities in conjunction with the Project,
whether on or off the Entire Property, except (i) as expressly provided for in the Existing
Land Use Regulations, Existing Development Approvals or Future Development
Approvals, or (ii) as expressly set forth in the provisions of this Agreement. If the scope
of the Project is changed with the consent of the Developer in a manner that increases
the Projects effect on the City s street, transit or utility facilities, in such case, any
requirement for such additional dedication, conveyance, transfer, construction or
installation shall be limited to that supported by a sufficient nexus and necessary to
accommodate the Project change. Any necessary CEQA analysis shall be conducted
to examine such incremental change. Developer shall also be entitled to credit and/or
reimbursement for the reservation or dedication of land or the installation of public
improvements, in accordance with any future written policy of the City concerning fee
credits and /or reimbursements for the reservation or dedication of land and the
installation of public improvements. Pursuant to Section 202 of Resolution No. 6469,
the public improvements to be constructed and dedicated to the City in connection with
the Project shall be those listed in Exhibit "F ", and the amount of Development Impact
Fees that shall be deemed satisfied by such construction and dedication shall be
approximately the amount set forth in Exhibit "G ".
(d) Development Exactions. Except as otherwise expressly set
forth in this Agreement and as authorized under the Existing Development Approvals,
City shall not impose Development Exactions in conjunction with Developer's
development of the Entire Property, or any part thereof or the Project, or any part
thereof, excepting only those Development Exactions that are authorized by the Existing
Development Approvals and Existing Land Use Regulations. A schedule of payment of
Development Impact Fees applicable to the Project is attached hereto as Exhibit "D"
and incorporated by reference herein. Pursuant to Section 202 of Resolution No. 6469,
the amount of such Development Impact Fees shall not be increased, nor shall the City
attempt to apply to the Entire Property, or any part thereof or the Project, or any part
thereof, any new or different Development Impact Fees, during the first five (5) years
following the full execution of this Agreement. Nothing contained in this Agreement
11
shall affect the ability of the City to collect Development Impact Fees that have been
adopted and imposed by a public agency other than the City.
(e) Future Environmental Review. The potential environmental
impacts of the Project were analyzed in the FEIR. Future Development Approvals will
be reviewed in light of the FEIR to determine if any additional environmental
documentation will be required. The determination will be made consistent with the
applicable provisions of CEQA and the State and local CEQA Guidelines.
(f) Other Governmental Permits. After City has approved the
Project, City shall cooperate, at no direct cost to City, with Developer in its efforts to
obtain such additional permits and approvals as may be required by any other
governmental or quasi - governmental agencies having jurisdiction over such portion of
the Project; provided permits and approvals are consistent with City's approval(s) and
are consistent with this Agreement. City does not warrant or represent that any other
governmental or quasi - govern mental permits or approvals will be granted.
(g) City Review of Applications for Future Development Approvais.
All subsequent consideration by City of Developer's applications for Future
Development Approvals for the Project shall be subject to the terms and conditions set
forth in this Agreement. City shall not disapprove, condition, or delay the processing of
any applications for any Future Development Approval for reasons inconsistent with the
Existing Land Use Regulations, the Existing Development Approvals, or the express
provisions of this Agreement. Upon satisfactory completion by Developer of all required
preliminary actions and payments of then applicable Filing or Processing Fees, if any,
City shall, in accordance with and subject to.Existing Land Use Regulations, Existing
Development Approvals, Future Development Approvals and all other legal
requirements, initiate, process, and complete all required steps, and act upon any
approvals and permits necessary for the development of the Project by Developer in as
prompt and diligent a manner as it performs such actions for other development projects
and in accordance with this Agreement, including, but not limited to, (i) the processing of
applications for and issuing of all discretionary approvals requiring the exercise of
judgment and deliberation by City, including without limitation, the Future Development
Approvals; (ii) the holding of any required public hearings; and (iii) the processing of
applications for and issuing of all ministerial approvals requiring the determination of
conformance with the Existing Development Approvals, Existing Land Use Regulations
and Future Development Approvals. If City is unable to process any of Developer's
applications for Future Development Approvals in a timeframe acceptable to Developer,
Developer shall provide written notice to City requesting aid in such processing. Upon
Developer's written request, City shall engage qualified outside consultants reasonably
acceptable to Developer to aid in such processing, provided that Developer shall be
required to reimburse to City, within thirty (30) days of invoicing by City, all reasonable
and direct charges to be incurred by City for such outside consultants. In this regard,
Developer, in timely manner, will provide City with all documents, applications, plans
and other information necessary for City to carry out its obligations hereunder and will
cause Developer's planners, engineers, and all other consultants to submit in a timely
manner all required materials and documents therefor. The Term of this Agreement
12
shall be automatically extended for the time period commencing as of the receipt by City
of Developer's written request for aid and ending on the date that such consultant
actually begins work on the Project ( "Processing Delay').
(h) Vested Rights to Future Development. After the date that City
approves an application for a Future Development Approval, Developer shall have the
vested right to develop pursuant to said Future Development Approval to the same
extent that Developer has the vested right to develop pursuant to the Existing
Development Approvals and the Existing Land Use Regulations. Upon City approval of
Future Development Approvals they will automatically become part of the Existing
Development Approvals.
(i) Conflicting Enactments. With the exception of those changes
authorized by the Reserved Powers, any other change in the Existing Land Use
Regulations or Existing Development Approvals, including, without limitation, any
change in the General Plan, zoning, or subdivision law, adopted or becoming effective
after the Effective Date, and adopted in any form by the City Council, the Planning
Commission or any other board, commission or department of City, or any officer or
employee thereof, or by the electorate (including, without limitation, by initiative or
referendum), as the case may be, that would, absent this Agreement, otherwise be
applicable to the Entire Property, or any part thereof, or the Project, or any part thereof,
and that would either: (x) conflict in any way with the Existing Land Use Regulations or
Existing Development Approvals (and, once issued, the future Development Approvals);
or (y) be more restrictive, burdensome or costly to the Entire Property, or any part
thereof or the Project, or any part thereof, than would be the case under the Existing
Land Use Regulations and Existing Development Approvals (and, once issued, the
Future Development Approvals) shall not be applied by City to any part of the Entire
Property, or any part thereof or the Project, or any part thereof. In addition to the
foregoing, unless provided for in the Existing Land Use Regulations or Existing
Development Approvals or Future Development Approvals or except to the extent the
Project is changed with the consent of the Developer thus necessitating any of the
following, the following shall be considered in direct conflict with this Agreement:
(a) Limits on Density and Intensity. Limiting or reducing the density
or intensity of all or any part of the Project, inconsistent with the Specific
Plan or this Agreement.
(b) Location of Improvements. Limiting the location of or increasing
or decreasing the size of buildings, or requiring grading, or other
improvements for the Commercial Entertainment Center in a manner that
is inconsistent with the Specific Plan or not required of other commercial
projects in the City.
(c) Discriminatory Application of Ordinances. Applying to the
Project or the Entire Property any Land Use Regulations, or interpreting or
enforcing any Land Use Regulation in a stricter or more demanding
fashion than was theretofore applied anywhere else within City or in a
13
manner that is not uniformly applied on a City -wide basis to all
development projects or project sites in City.
(d) Exactions. Imposing any Development Exaction, requirement,
condition, or other restriction on the Project that is not expressly contained
within this Agreement, any Existing Development Approval (including the
Specific Plan), or Existing Land Use Regulations.
The above list of actions is not intended to be comprehensive, but is illustrative of the
types of actions that would conflict with this Agreement.
Notwithstanding the foregoing, this Agreement shall not preclude the application to the
Project of rules, regulations, ordinances and officially adopted plans and policies in
conflict with the Existing Land Use Regulations, Development Approvals, Future
Development Approvals or Existing Land Use Regulations where such additional rules,
regulations, ordinances and officially adopted plans and policies are mutually agreed to
in writing by Developer and the City in accordance with this Agreement.
Q) Permitted Conditions. Provided Developer's applications for
any Future Development Approvals are consistent with the development of the Project
under this Agreement, the Existing Land Use Regulations and Existing Development
Approvals, City shall, subject to the Reserved Powers, grant the Future Development
Approvals in accordance with the Existing Land Use Regulations, the Existing
Development Approvals and this Agreement. City shall have the right to impose
reasonable conditions in connection with Future Development Approvals provided,
however, that such conditions shall not be inconsistent with this Agreement, the Existing
Development Approvals or the Existing Land Use Regulations, or more restrictive,
burdensome or costly to the Project than the Existing Land Use Regulations and
Existing Development Approvals, or create delays for the development of the Entire
Property, or any part thereof or the Project, or any part thereof,.
(k) Time Period of Tentative Maas. To the extent permitted by law,
the term of (1) any tentative map, parcel map, vesting tentative map or vesting parcel
map that may be approved for the Project, (ii) any amendment (or reconfiguration) of
any such map (including any lot line adjustment or merger of lots within such a map), or
(iii) any other map for any part of the Property filed prior to the termination of this
Agreement, shall automatically be extended for the Term of this Agreement.
7. Acknowledgements Agreements and Assurances on the Part of the
Parties. In order to effectuate the provisions of this Agreement, and in consideration for
the Parties entering this Agreement and obligating themselves to cant' out the
covenants and conditions set forth in Section 6 and Section 7 of this Agreement, the
Parties hereby agree and acknowledge that:
(a) Administrative Changes and Modifications. The Parties
acknowledge that further planning and development of the Project may demonstrate
that refinements and changes are appropriate with respect to the details and
14
performance of the Parties under this Agreement. The Parties desire to retain a certain
degree of flexibility with respect to the details of the Project development and with
respect to those items covered in general terms under this Agreement, the Existing
Development Approvals, the Existing Lang Use Regulations, and, once issued, any
Future Development Approvals. If and when the Parties find that "Substantially
Conforming Changes," as herein defined, are necessary, desirable or appropriate, they
shall, unless otherwise required by law, effectuate such changes or adjustments
through administrative modifications executed by the Developer and the Director or his
or her designee. As used herein, "Substantially Conforming Changes" are changes,
modifications or adjustments that are those changes that are deemed to be in
substantial conformance under the Specific Plan. Substantially Conforming Changes
shall not be deemed to be an amendment to this Agreement and /or the Existing
Development Approvals, and Substantially Conforming Changes shall not require prior
notice or hearing by the Planning Commission or City Council.
(b) Moratorium. Subject to the City's exercise of its Reserved
Powers, no City- imposed moratorium or other limitation, relating to the rate, timing or
sequencing of the development or construction of all or any part of the Project, whether
imposed by ordinance, initiative, referendum, resolution, policy, order or otherwise, and
whether enacted by the Council, an agency of City, the electorate, or affecting the rate,
timing or sequencing of parcel or subdivision maps (whether tentative, vesting tentative
or final), building permits, occupancy certificates or other entitlements to use or service
approved, issued or granted within City, or portions of City, shall apply to the Project.
(c) Timing of Development. Because the California Supreme Court
held in Pardee Construction Co. v. City of Camarillo, 37 Cal.3d 465 (1984) that the
failure of the parties to provide for the timing of development allowed a later- adopted
initiative that restricted the timing of development to prevail over the parties' agreement,
it is the intent of Developer and the City to cure any such deficiency by acknowledging
and providing that Developer shall have the right (without the obligation) to develop the
Project and the Entire Property in such order and at such rate and at such time as it
deems appropriate within the exercise of its subjective business judgment.
8. Public Benefits. The Parties acknowledge that significant public benefits
will be derived from the following covenants of Developer:
(a) Development Agreement Fee. Notwithstanding any provision
herein to the contrary, SAA shall pay to City a development agreement fee totaling Two
Million Dollars ($2,000,000.00) payable in cash, cashier's check or otherwise
immediately available funds. Such payment shall be made by SAA to City as a
condition precedent to the issuance of the first building permit associated with the
Project.
(b) Well Site. Notwithstanding any provision herein to the contrary,
and notwithstanding that the City has no current plans to develop a municipal water well
on any portion of the Entire Property and merely desires to reserve the right to do so,
Owner shall cause to be dedicated, in fee simple, to the City a municipal water well site
15
0
of approximately Five Thousand (5,000) to Fifteen Thousand (15,000) (as determined
by City, depending on whether water treatment capabilities are required) square feet,
within an existing parking area and in such an area as to minimize any reduction in
parking area, traffic impacts and in a location so as to not impact buildings proposed by
the Project. The precise location of such well site shall be approved by Developer, in
Developer's reasonable discretion. Such dedication shall be made by means of a
recordable instrument, in a form approved by the City Attorney. Such instrument shall
be delivered to City within thirty (30) days following Developer's receipt a written request
for same by City. If the City ever determines to construct a municipal water well as
provided above, any construction of a well on such well site shall be subject to
compliance with CEQA, and the exterior design shall be consistent with the design
guidelines of the Specific Plan.
(c) Tenant Character and Quality. Notwithstanding any provision
herein to the contrary, SAA covenants that, for the Term of this Agreement, the
Commercial Entertainment Center shall meet the following criteria. The tenant mix shall
be consistent with a first -class shopping center and shall include upscale tenants such
as those tenants who occupy space at any one or more of the following regional
shopping centers: Newport Beach's Fashion Island, Costa Mesa's South Coast Plaza,
the Grove adjacent to the Farmer's Market, and Glendale's Americana on Brand.
9. Cooperation and Implementation. City and Developer agree that they will
cooperate with one another to the fullest extent reasonable and feasible to implement
this Agreement. Such cooperation shall include, but is not limited to, the following:
(a) Further Actions and Instruments. Each Party shall cooperate
with and provide reasonable assistance to the other Party to the extent necessary to
implement this Agreement. Upon the request of either Party at any time, the other Party
shall promptly execute, with acknowledgment or affidavit if reasonably required, and file
or record such required instruments and writings, including estoppel certificates, and
take any actions as may be reasonably necessary to implement this Agreement or to
evidence or consummate the transactions contemplated by this Agreement.
(b) Approvals. Reasonableness. Except when this Agreement
specifically authorizes a Party to withhold its approval or consent in its sole and
absolute discretion, when either City or Developer shall require the approval or consent
of the other Party in fulfilling any covenant, provision, or condition set forth herein, such
approval or consent shall not be unreasonably withheld, conditioned, or delayed by the
Party from whom such approval or consent is sought.
(c) Processing During Third Party Litigation. The filing of any third
party lawsuit(s) against City and/or Developer relating to this Agreement, the Existing
Development Approvals, Existing Land Use Approvals, Future Development Approvals,
or to other Development Approvals affecting the Entire Property, or any part thereof or
the Project, or any part thereof, shall not, unless agreed to by Developer, delay or stop
the development, processing or construction of the Project, or any part thereof, or of the
Entire Property, or any part thereof, the approval of the Future Development Approvals,
16
0
0 0
or the issuance of ministerial approvals, unless the third party obtains a court order
preventing the activity. City shall not stipulate to or fail to oppose the issuance of any
such order. In the absence of such a court order, Developer shall have the right
(without the obligation but at its sole risk) to develop the Project and the Entire Property
in such order and at such rate and at such time as it deems appropriate within the
exercise of its subjective business judgment, as provided for under Section 7(c).
(d) Defense of Agreement and Development Approvals. In the
event of any legal action instituted by a third party, including without limitation any other
governmental entity or official, challenging the validity of this Agreement, any of the
Existing Development Approvals, the Existing Land Use Regulations, or any Future
Development Approval granted pursuant to this Agreement, or any element thereof or
the proceedings, acts, or determinations taken, done or made prior to such matters, or
the right of either Party to engage in the acts and transactions contemplated by this
Agreement, upon the election of the Developer to defend against the lawsuit, the Parties
agree to cooperate fully with each other in defending such action (including any actions
reasonably requested to mitigate the impact of such action). Developer shall, at its sole
cost and expense, indemnify, defend and hold harmless, the City, its officials, officers
and employees for any damage or liability incurred by the same while acting within the
scope of their official duties, as the result of the City's obligation hereunder to not stop
the development, processing or construction of any portion of the Project, the approval
of any Future Development Approvals, or the issuance of ministerial approvals. The
City shall have the absolute right to retain such legal counsel as the City deems
necessary and appropriate; provided however, that the City shall consult with Developer
in the selection of such legal counsel. In the event of any such third party action or
proceeding, Developer's counsel shall assume the lead counsel role in the defense of
such action or proceeding, and the City's counsel shall assume a review and approval
role. The lead counsel role shall include, without limitation, the following types of duties:
gathering and organizing documents for the preparation of the administrative record,
preparation of motions, briefs and other court pleadings, assuming the lead role in oral
arguments and other court appearances, propounding and responding to any discovery
requests if discovery is permitted pursuant to applicable law. The review and approval
counsel role shall include, the following types of duties: reviewing and approving
documents for the preparation of the administrative record, reviewing and approving
motions, briefs and other court pleadings, attending (but not assuming the lead role in)
oral arguments and other court appearances, reviewing and approving any discovery
requests and responses to any discovery requests if discovery is permitted pursuant to
applicable law. Developer shall be obligated to reimburse the City for only those
reasonable legal fees and costs incurred in connection with the review and approvals of
the City's counsel that are set forth in the immediately preceding sentence that are
incurred in any such third party action or proceeding. To the extent this Section 9(d) is
inconsistent with that certain reimbursement agreement entered into between the City
and Caruso Management, Inc., dated June 15, 2005, the provisions of this Section 9(d)
shall prevail. The duty of Developer to indemnify, defend and hold harmless the City
shall not apply to the extent that any damage or liability is the result of the breach of this
Agreement by, or the willful misconduct or gross negligence of, the City, its officials,
officers or employees. In the event Developer chooses not to indemnify, defend and
17
9 0
hold harmless (or any combination thereof) as required by this Section, the City, its
officials, officers and employees shall be under no obligation to indemnify any party,
defend any such action, or hold harmless any party.
10. Compliance: Default.
(a) Periodic Review. The City shall review this Agreement
annually, on or before the anniversary of the Effective Date, in order to ascertain the
good faith compliance by Developer with the terms of the Agreement. Developer shall
submit an Annual Monitoring Report, in substantially the form attached hereto as
Exhibit "E ", within ten (10) days after written notice from the City Manager. The Annual
Monitoring Report shall be accompanied by an annual review and administration fee
sufficient to defray the actual reasonable and direct City costs of review of the
Monitoring Report.
(b) Special Review. A special review ( "Special Review ") of
compliance with this Agreement may be made either by agreement of the Parties or by
initiation in one or more of the following ways following the issuance of a Notice of Non -
Compliance to Developer and an opportunity to cure any alleged breach pursuant to
Section 10 (j):
(1) Recommendation of the Development Services Department
staff,
(2) Affirmative vote of at least three (3) members of the Planning
Commission: or
(3) Affirmative vote of at least three (3) members of the City
,dal!
(c) Procedure. During either a periodic review or a special review,
Developer shall be required to demonstrate good faith compliance with the terms of the
Agreement. The burden of proof on this issue shall be on Developer.
(d) Upon completion of a periodic review or a special review, the
Director shall submit a report to the Planning Commission setting forth the evidence
concerning good faith compliance by Developer with the terms of this Agreement and
his or her recommended finding on that issue. The Planning Commission shall consider
such report at a public hearing. The City Manager or designee shall provide notice to
Developer at least ten (10) days prior to the hearing by the Planning Commission.
(e) If the Planning Commission finds and determines on the basis
of substantial evidence that Developer has complied in good faith with the terms and
conditions of this Agreement, the review shall be concluded.
(f) If the Planning Commission finds and determines on the basis
of substantial evidence that Developer has not complied in good faith with the terms and
conditions of this Agreement, the Commission shall state with reasonable specificity and
if?
41 0
particularity the nature of the Developer's default and the facts supporting such
determination and the Commission may recommend to the City Council to modify or
terminate this Agreement. Developer may appeal a Planning Commission
determination pursuant to this Section 10(f) pursuant to City's procedural rules for
consideration of appeals in zoning matters then in effect; provided however, that any
substantive rules shall be pursuant to the Existing Land Use Regulations.
(g) Proceedings Upon Modification or Termination. If, upon a
finding under Section 10(f), City determines to proceed with modification or termination
of this Agreement, City shall give written notice to Developer and Mortgagee ( as
defined in Section 15(b) and as provided in Section 15(d)) of its intention so to do. The
notice shall be given at least ten (10) calendar days prior to the scheduled hearing and
shall contain:
(1) The time and place of the hearing;
(2) A statement as to whether or not City proposes to
terminate or to modify the Agreement; and,
(3) Such other information that the City considers necessary
to inform Developer of the nature of the proceeding.
(h) Hearing on Modification or Termination. At the time and place
set for the hearing on modification or termination pursuant to Section 10(g), Developer
shall be given an opportunity to be heard and Developer shall be required to
demonstrate good faith compliance with the terms and conditions of this Agreement.
The burden of proof on this issue shall be on Developer. If the City Council finds, based
upon substantial evidence, that Developer has not complied in good faith with the terms
or conditions of the Agreement, the City Council may terminate this Agreement or
modify this Agreement and impose such conditions as are reasonably necessary to
protect the interests of the City. The decision of the City Council shall be final, subject
only to judicial review pursuant to Section 1094.5 of the Code of Civil Procedure.
(i) Certificate of Agreement Compliance. If, at the conclusion of a
Periodic or Special Review, Developer is found to be in compliance with this
Agreement, City Manager or designee shall, upon request by Developer, issue a
Certificate of Agreement Compliance ( "Certificate ") to Developer stating that after the
most recent Periodic or Special Review and based upon the information known or made
known to the Director and City Council that: (1) this Agreement remains in effect; and
(2) Developer is not in default. The Certificate shall be in recordable form, shall contain
information necessary to communicate constructive record notice of the finding of
compliance, shall state whether the Certificate is issued after a Periodic or Special
Review and shall state the anticipated date of commencement of the next Periodic
Review. Developer may record the Certificate with the County Recorder. Whether or
not the Certificate is relied upon by assignees or other transferees or Developer, City
shall not be bound by a Certificate if a default existed at the time of the Periodic or
19
Special Review, but was concealed from or otherwise not known to the Director or City
Council.
0) Notice and Opportunity to Cure for Breaches. If at any time
either Party reasonably concludes that the other Party (i) has not acted in reasonable
prima facie compliance with this Agreement, and (ii) is out of compliance with a specific
material term or provision of this Agreement, then that Party may issue and deliver to
the breaching Party a written Notice of Non - Compliance, detailing the specific reasons
of non - compliance (including references to sections and provisions of this Agreement
that have allegedly been breached) and a complete statement of all facts demonstrating
such non- compliance. The Parties shall also meet with each other as appropriate to
discuss any alleged non - compliance. A Party shall have thirty (30) calendar days
following its receipt of the Notice of Non - Compliance in which to cure said failure(s);
provided, however, that if any one or more of the item(s) of non - compliance set forth in
the Notice of Non - Compliance cannot reasonably be cured within said thirty (30)
calendar day period, then the Party receiving such Notice shall not be in breach of this
Agreement if it commences to cure said item(s) within said thirty (30) day period and
diligently prosecutes said cure to completion.
(k) Termination of Development Aareement as to Breaching Party.
If Developer fails to timely cure any item(s) of non - compliance set forth in a written
Notice of Non - Compliance issued pursuant to Section 100), then the City shall have the
right, but not the obligation, to initiate proceedings under Resolution No. 6469 for the
purpose of modifying or terminating this Agreement. Such proceedings shall be initiated
by written notice to the Developer and Mortgagee. If the City determines to terminate
this Agreement following a reasonable opportunity for the Developer to cure any non-
performance, the City shall give Developer and Mortgagee written notice of its intent to
so terminate this Agreement, specifying the precise grounds for termination and setting
a date, time and place for a public hearing before the City Council on the issue,
pursuant to Section 100). At the noticed public hearing, Developer and/or its
designated representative shall be given an opportunity to make a full and public
presentation to the City. If, following the taking of evidence and hearing of testimony at
said public hearing, the City finds, based upon a preponderance of evidence, that the
Developer has not demonstrated compliance with any material term of this Agreement,
and that Developer is out of material compliance with a specific, substantive term or
provision of this Agreement, then the City may (unless the Parties otherwise agree in
writing) terminate this Agreement. The decision of the City Council shall be final,
subject only to judicial review pursuant to Section 1094.5 of the Code of Civil
Procedure.
11. Amendment or Modification. Except for Substantially Conforming
Changes as defined under Section 7(a), or a modification following proceedings
instituted pursuant to Section 10 hereof, this Agreement may be amended or modified
from time to time only with the written consent of Developer and the City or their
successors and assigns, and only upon approval of an amendment by the City Council
after a public hearing pursuant to Government Code Section 65868.
20
•
12. Term of Agreement. This Agreement shall become operative on the
Effective Date and the "Terre" of this Agreement shall end five (5) years after the
Effective Date, unless this Agreement is terminated, modified or the Term is extended
upon mutual written consent of the Parties hereto or as otherwise provided by this
Agreement. The initial five (5) year term of this Agreement may be extended by the
Parties for an additional three (3) years provided that: (a) Developer provides at least
180 days written notice to City prior to expiration of the initial term; and (b) at or before
the expiration of the Term, as such Term may be extended as provided for in Section
6(g) for the period of any City Processing Delay, and as specified in Section 19 by the
number of days equal to the delay caused by any Enforced Delay, at least one (1)
building permit has been issued for a building included within the Project; and (c)
Developer is not then in uncured default under the Agreement. For purposes of clause
(b), above, the Parties hereby agree that any decision by the City Council to not extend
the Term shall be conclusively deemed "reasonable" if the first building permit has not
yet been issued as of the expiration of the initial Term of this Agreement, subject to the
provisions of the final sentence of this Section. No notice or public hearing need be
conducted prior to any such extension. Following expiration or termination of the initial
Term and any extension thereof, this Agreement shall be deemed terminated and of no
further force and effect. The Term, including both the initial Term and any extension,
shall be extended as provided for in Section 6(g) for the period of any City Processing
Delay, and as specified in Section 19 by the number of days equal to the delay caused
by any Enforced Delay.
13. Administration of Agreement and Resolution of Disoutes.
(a) Administration of Disputes. Subject to Sections 10(h) and 10(k),
all disputes involving the enforcement, interpretation, or administration of this
Agreement (including, but not limited to, decisions by the City staff concerning this
Agreement and the Project or other matters concerning this Agreement that are the
subject hereof and also including the adoption of any Implementing Regulation) shall
first be subject to good faith negotiations between the Parties to resolve the dispute. In
the event the dispute is not resolved by negotiations, the dispute shall then be heard
and decided by the City Council within thirty (30) days following receipt of a written
request by any Party therefor. Thereafter, any decision of the City Council that remains
in dispute shall be appealed to, heard by, and finally resolved pursuant to the
Alternative Dispute Resolution procedures set forth in Section 13(b) below. Nothing in
this Agreement shall prevent or delay Developer or City from seeking a temporary or
preliminary injunction in state or federal court if it believes that injunctive relief is
necessary on a more immediate basis.
(b) Alternative Dispute Resolution. After the provisions of Section
13(a) above have been complied with, subject to the provisions of the final sentence of
Section 10(k), all disputes regarding the enforcement, interpretation, termination,
modification or administration of this Agreement shall be heard and resolved pursuant to
the alternative dispute resolution procedure set forth in this Section 13(b). All matters to
be heard and resolved pursuant to this Section 13(b) shall be heard and finally resolved
by a single arbitrator who shall be a retired judge from either the California Superior
21
Court, the California Court of Appeals, the California Supreme Court, the United States
District Court or the United States Court of Appeals. This arbitrator shall be selected by
mutual agreement of the Parties. In the event that the Parties are unable to agree upon
the selection of an arbitrator within twenty (20) days following the expiration of the thirty
(30) day time period for the City Council's action on the dispute in subsection (a) of this
Section, then any Party may petition the Superior Court of Los Angeles County for the
appointment of the arbitrator pursuant to the procedures specified in Code of Civil
Procedure Section 1281.6. Upon appointment of the arbitrator, the matter shall be set
for arbitration at a time not less than thirty (30) nor more than ninety (90) days from the
effective date of the appointment of the arbitrator. The arbitration shall be conducted
under the procedures set forth in Code of Civil Procedure Section 1280 at seq., or under
such other procedures as are agreeable to both Parties, except that the provisions of
the Califomia Code of Civil Procedure pertaining to discovery and the provisions of the
California Evidence Code shall be applicable to such proceeding and either Party shall
have the right to appeal the final decision of the arbitrator. The cost of the arbitrator
shall be bome by the non - prevailing party (as that term is used in the Califomia Civil
Code) as set forth in Section 23 of this Agreement concerning attorneys' fees and costs.
(c) Injunctive Relief. Any Party to the dispute may, in addition to
any other rights or remedies provided by this Agreement, seek to enjoin any threatened
or attempted violation hereof, seek a stay pursuant to the provisions of Califomia Code
of Civil Procedure Section 1094.5(g), or enforce by specific performance the obligations
and rights of the Parties hereto, except as otherwise provided herein.
(d) No Personal Liability. No board member, councilmember,
official or employee of the City shall be personally liable to Developer in the event of any
default or breach by the City for any amount that may become due to Developer or on
any obligations under the terms of this Agreement. No board member, partner,
member, manager, officer or employee of the Developer shall be personally liable to
City in the event of any default or breach by the Developer for any amount that may
become due to City or on any obligations under the terms of this Agreement.
(e) Monetary Damages Limited. It is acknowledged by the Parties
that neither Party would have entered into this Agreement if it were to be liable in an
unlimited amount of monetary damages under this Agreement, or with respect to this
Agreement or the application thereof. In general, each of the Parties hereto may pursue
any remedy at law or equity available for the breach of any provision of this Agreement.
Except as provided in this paragraph, neither Party shall be liable in damages to the
other, or to any respective successor in interest of or to any other person, and both
Parties covenants not to sue for damages or claim any damages:
(1) For any breach of this Agreement or for any cause of
action that arises out of this Agreement; or
(2) For the taking, impairment or restriction of any right or
interest conveyed or provided under or pursuant to this Agreement (provided, however,
22
0 0 P,(
that this provision shall not authorize any taking of property without payment of just
compensation); or
(3) Arising out of or connected with any dispute, controversy
or issue regarding the application or interpretation or effect of the provisions of this
Agreement;
provided however, that the Parties may be liable to one another or their
successors in interest, and the Parties may sue one another for damages, including
attorneys fees and costs, of up to Two Million Dollars ($2,000,000).
(f) Specific Performance. The Parties acknowledge that money
damages and remedies at law generally are inadequate and specific performance and
other non - monetary relief are particularly appropriate remedies for the enforcement of
this Agreement and should be available to all Parties for the following reasons:
(1) Unlimited money damages are unavailable as provided
above.
(2) Due to the size, nature and scope of the Project, it may
not be practical or possible to restore the Entire Property, or any portion thereof, to its
natural condition once implementation of this Agreement has begun. After such
implementation, Developer may be foreclosed from other choices it may have had to
utilize the Entire Property or portions thereof. Developer has invested significant time
and resources and performed extensive planning and processing of the Project in
agreeing to the terms of this Agreement and will be investing even more significant time
and resources in implementing the Project in reliance upon the terms of this Agreement,
and it is not possible to determine the sum of money that would adequately compensate
Developer for such efforts.
14. Transfers and Assignments.
(a) Rights to Assign. Except as provided in Section 15(a),
Developer may not assign or transfer its rights or obligations under this Agreement
without the prior written consent of City. Notwithstanding the foregoing, Developer shall
have the right to assign, transfer or otherwise convey its interests, rights or obligations
hereunder: (i) in whole or in part, to an entity under common control with Caruso or its
members; and (ii) in part, with respect to one or more building pads on the Property, to
one or more subtenants for the purpose of constructing building(s) thereon in
accordance with the Specific Plan, without approval or consent of the City, provided that
Developer provides reasonable evidence thereof to City and gives thirty (30) days' prior
written notice of the proposed transfer to the City Manager, and Developer provides City
with notice of the name and address of the transferee within ten (10) days of the
effective date of the transfer. A person or entity approved hereunder for a transfer of all
or any part of the Developer's rights and obligations under this Agreement shall be
known as a 'Transferee ". Upon the effective date of any sale, lease, sublease, or other
transfer or assignment, the seller, lessor, sublessor, or other transferor or assignor
23
automatically shall be released from any executory obligations to City hereunder with
respect to the portion of the Entire Property sold, leased, subleased, transferred or
assigned; provided, however, that unless City releases the seller, lessor, sublessor, or
other transferor or assignor in writing, it shall remain responsible to City for performance
of any obligations as to which it was in default as of the effective date of the transfer.
(b) Liabilities Upon Transfer. Upon the delegation of all duties and
obligations and the sale, lease, sublease, transfer or assignment of all or any portion of
the Entire Property to a Transferee, Developer shall be released from its obligations
under this Agreement with respect to the Entire Property or portion thereof so
transferred arising subsequent to the effective date of such transfer if (1) Developer has
provided to City thirty (30) days' prior written notice of such transfer and (2) the
Transferee has agreed in a writing, the form and substance of which has been
reasonably approved by the Director, to be subject to all of the provisions and
obligations hereof applicable to the portion of the Entire Property so transferred. Upon
any transfer of any portion of the Entire Property and the express assumption of
Developer's obligations under this Agreement by such Transferee, the Transferee
becomes a Party to this Agreement with respect only to the portion of the Entire
Property acquired by the Transferee, and the City agrees to look solely to the
Transferee for compliance by such Transferee with the provisions of this Agreement as
such provisions relate to the portion of the Entire Property acquired by such Transferee.
Any such Transferee shall be entitled to the benefits of this Agreement and, except as
otherwise provided in Section 15 below, shall be subject to the obligations of this
Agreement, applicable to the parcel(s) transferred. Notwithstanding any provision in
this Agreement expressly or impliedly to the contrary, no Transferee shall have the right
to amend or modify this Agreement in any respect whatsoever with respect to that
portion of the Entire Property that is not acquired by the Transferee. A default by any
Transferee shall only affect that portion of the Entire Property owned, leased or
subleased by such Transferee. Except as otherwise provided in Section 15 below, the
Transferee shall be responsible for the reporting and annual review requirements
relating to the portion of the Entire Property owned, leased or subleased by such
Transferee, and any amendment to this Agreement between City and a Transferee shall
only affect the portion of the Entire Property owned, leased or subleased by such
Transferee. In the event that Developer retains its obligations under this Agreement
with respect to the portion of the Entire Property transferred by Developer, the
Transferee in such a transaction (a "Non - Assuming Transferee ") shall be deemed to
have no obligations under this Agreement, but shall continue to benefit from all rights
provided by this Agreement for the duration of the Term of this Agreement. Nothing in
this Section shall exempt any Non - Assuming Transferee from payment of applicable
fees and assessments or compliance with applicable permit conditions of approval or
the Mitigation Monitoring and Reporting Program.
15. Mortgagee Rights.
(a) Encumbrances on the Entire Property. The Parties hereto
agree that this Agreement shall not prevent or limit Developer, at Developer's sole and
absolute discretion, from encumbering the Entire Property or any estate or interest
24
0 0 R
therein, including the leasehold interest in the Ground Lease, or any portion thereof, or
any improvement thereon, in any manner whatsoever by one or more mortgages, deeds
of trust, sale and leaseback, or other form of secured financing ( "Mortgage ") with
respect to the construction, development, use or operation of the Project and parts
thereof.
(b) Mortgagee Protection. To the extent legally permissible, this
Agreement shall be superior and senior to any lien placed upon any portion of the Entire
Property, or any portion thereof, including the lien of any Mortgage. Notwithstanding the
foregoing, no breach of this Agreement shall defeat, render invalid, diminish, or impair
the lien of any Mortgage made in good faith and for value. Any acquisition or
acceptance of title or any right or interest in or with respect to the Entire Property or any
portion thereof, including the leasehold estate created by the Ground Lease, by the
holder of a Mortgage (a "Mortgagee "), pursuant to foreclosure, trustee's sale, deed in
lieu of foreclosure, lease or sublease termination or otherwise, shall be subject to all of
the terms and conditions of this Agreement except that any such Mortgagee, including
its affiliate and any purchaser at a foreclosure, trustee's sale or deed in lieu of
foreclosure, lease or leaseback who takes title to the Entire Property or any portion
thereof, including the leasehold estate created by the Ground Lease, shall be entitled to
the benefits arising under this Agreement provided Mortgagee complies with Section
15(c) below.
(c) Mortgagee Not Obligated. Notwithstanding the provisions of
this Section 15, Mortgagee will not have any obligation or duty pursuant to the terms set
forth in this Agreement to perform the obligations of Developer or other affirmative
covenants of Developer hereunder, or to guarantee such performance, except that the
Mortgagee and its successor, including any purchaser at a foreclosure sale, shall have
no vested right to develop the Project without fully complying with the terms of this
Agreement and executing and delivering to City, in a form and with terms reasonably
acceptable to City, an assumption agreement of Developer's obligations hereunder.
(d) Request for Notice to Mortgage. The Mortgagee of any
Mortgage encumbering the Entire Property, or any portion thereof, including the
leasehold estate created by the Ground Lease, who has submitted a request in writing
to City in the manner specified herein for giving notices shall be entitled to receive
written notification from City of any Notice of Non - Compliance by Developer in the
performance of Developer's obligations under this Agreement.
(e) Mortgagee's Time to Cure. If City timely receives a request
from a Mortgagee requesting a copy of any Notice of Non - Compliance given to
Developer under the terms of this Agreement, City shall provide a copy of that notice to
the Mortgagee within ten (10) days of sending the Notice of Non - Compliance to
Developer.
(f) Mortgagee Rlghts and Obligations. The Mortgagee of the
Entire Property, or any portion thereof, shall, upon written request to City, be entitled to
receive from City written notification of any default by Developer of the performance of
25
Developer's obligations under the Agreement which has not been cured within thirty (30)�
days following the date of default, provided that the failure of City to provide such
required notice shall not constitute a material breach of this Agreement nor shall it affect
the status of such Developer default other than that the period of time for the
Mortgagee's right to cure the default shall not begin to run until it receives such notice.
(i) Right to Cure. Notwithstanding Developers default, this
Agreement shall not be terminated by City as to any Mortgagee to whom notice is
actually given and to which either of the following is true:
(a) The Mortgagee cures any default by Developer
involving payment of money within ninety (90) days after Mortgagee's receipt of written
notice of default;
(b) As to defaults requiring title or possession of the
Entire Property, or any portion thereof, to effectuate a cure: (a) the Mortgagee agrees in
writing, within ninety (90) days after receipt from City of the written notice of default, to
perform the proportionate share of Developer's obligations under this Agreement
allocable to that portion of the Entire Property in which the Mortgagee has an interest,
conditioned upon such Mortgagee's acquisition of the Entire Property, or portion thereof,
including the leasehold estate created by the Ground Lease, by foreclosure, trustee's
sale or deed in lieu of foreclosure, lease or leaseback; (b) the Mortgagee commences
proceedings to reacquire title to the Entire Property, or applicable portion thereof,
including the leasehold estate created by the Ground Lease, within said ninety (90)
days after receipt from City of the written notice of default and thereafter diligently
pursues such proceedings to completion; and (c) the Mortgagee promptly and diligently
cures such default after obtaining title or possession. Subject to the foregoing, in the
event any Mortgagee records a notice of default as to its Mortgage, upon the
Mortgagee's written request to assume Developer's obligations hereunder, City shall
consent to the assignment of all of Developer's rights and obligations under this
Agreement to the Mortgagee or to any purchaser at a foreclosure, trustee's sale or deed
in lieu of foreclosure, lease or leaseback, provided the Mortgagee or such purchaser
executes and delivers to City an assumption agreement in a form and with terms
reasonably acceptable to City, and Developer shall thereafter be released by City from
liability hereunder with regard to the applicable portion of the Entire Property that is
transferred in accordance with Section 14 above. Notwithstanding the foregoing, City
shall not impose any terms on the Mortgagee or any purchaser at a foreclosure,
trustee's sale or deed in lieu of foreclosure, lease or leaseback which are inconsistent
with the provisions of this Agreement.
(ii) Extended Cure Period. Notwithstanding Section 15(f)i(i)
above, if any Mortgagee or any purchaser at a foreclosure, trustee's sale or deed in lieu
of foreclosure, lease or leaseback is prohibited from commencing or prosecuting
foreclosure or other appropriate proceedings, including by any process of injunction
issued by any court or by reason of any action by any court having jurisdiction or any
bankruptcy or insolvency proceeding involving Developer, the times specified in Section
15(f)(i) above for commencing or prosecuting foreclosure or other proceedings or curing
26
2 0
any default by Developer, but not including the payment of money as provided in J
Section 15(f)(i)(a) above, shall be extended for the period of the prohibition.
(iii) Superior Lien. The lien of any existing or future Mortgage
recorded against all or any part of the Entire Property or interest therein, including the
leasehold interest under the Ground Lease, shall be superior and senior to any lien
created by this Agreement or the recordation thereof. At the request of any lender
whose loan will be secured by a Mortgage on all or any portion of the Entire Property,
including the leasehold estate created by the Ground Lease, City shall execute a
subordination agreement, subordinating City's interest hereunder to the lien of such
Mortgage, which subordination agreement shall be subject to the reasonable approval
of City. Notwithstanding the foregoing: (i) at the option of the Mortgagee, any
foreclosure of any such deed of trust shall not serve to extinguish or terminate this
Agreement, provided that in no event shall any dedications or conveyances made by
Developer to City be affected or reversed; and (ii) the lien of any real property bond or
assessment shall be superior to the lien of any deed of trust and this Agreement.
(iv) No Impairment of Lien. Neither entering into this Agreement
nor a breach of this Agreement shall defeat, render invalid, diminish or impair the lien of
any existing or future Mortgage on the Entire Property, or any portion thereof, including
the leasehold estate created by the Ground Lease, made in good faith and for value.
(v) Election to Assume Obligations. Except as provided to the
contrary in this Agreement, no Mortgagee or beneficiary shall have an obligation or duty
under this Agreement to perform the obligations of Developer or other affirmative
covenants of Developer hereunder, or to guarantee such performance, and no
Mortgagee shall be liable for any defaults or monetary obligations of Developer arising
prior to acquisition of title to the Entire Property or any portion thereof, including the
leasehold estate created by the Ground Lease, and the execution of an assumption
agreement as required by Section 15(c) above by such Mortgagee or their respective
successors or assigns; except that to the extent any covenant to be performed by
Developer is a condition to the performance of a covenant by City, the performance
thereof shall continue to be a condition precedent to City's performance hereunder. In
the event a Mortgagee or any purchaser at a foreclosure, trustee's sale or deed in lieu
of foreclosure, lease or leaseback elects to develop all or any portion of the Entire
Property in accordance with the Existing Development Approvals, Future Development
Approvals, Existing Land Use Regulations, the Mortgagee or any purchaser at a
foreclosure, trustee's sale or deed in lieu of foreclosure, lease or leaseback shall be
required to assume, in writing, and perform the obligations or other affirmative
covenants of Developer under this Agreement pursuant to Section 15(c) above.
(vi) Reguest to Modify. City acknowledges that the lenders
providing financing for the Project may require certain modifications to this Agreement
and City agrees, upon request from time to time, to meet with Developer and /or
representatives of such lenders to negotiate in good faith any such requirement for
modification. City will not unreasonably withhold its consent to any such requested
27
i •
interpretation or modification, provided such interpretation or modification is consistent
with the language, intent and purposes of this Agreement. To the extent that City
Council action is required in order to lawfully adopt the requested modification to this
Agreement, the City Council shall promptly and reasonably consider the request,
without imposing any additional conditions or Development Exactions from Developer
so long as such requested modification(s) do(es) not materially affect the terms of this
Agreement.
16. Notices. All notices under this Agreement shall be in writing and shall be
considered given either: (i) when delivered in person to the recipient named below; (ii)
on the date of delivery or refusal shown on the return receipt, after deposit in the United
States mail in a sealed envelope as either registered or certified mail with return receipt
requested, and postage and postal charges prepaid, and addressed to the recipient
named below; (iii) on the date of delivery or refusal, when delivered by Federal Express
or other commercial express delivery services providing acknowledgements of receipt;
or (iv) on the date of delivery when delivered by facsimile providing verification of
delivery and receipt. Such notices or communications shall be given to the Parties and
their respective counsel at their addresses set forth below:
To City: City of Arcadia
240 West Huntington Drive
P.O. Box 60021
Arcadia, California 91066
Attention: City Manager
FAX: (626) 446 -5729
With copies to: City Attorney, City of Arcadia
240 West Huntington Drive
P.O. Box 60021
Arcadia, California 91066
Attention: Steve Deitsch, City Attorney
FAX: (626) 574 -5407
To Developer: Caruso Affiliated
101 The Grove Drive
Los Angeles, California 90036
Attention: Rick J. Caruso
FAX: (323) 900 -8101
With copy to: Donfeld, Kelley & Rollman
11845 West Olympic Blvd, Suite 1245
Los Angeles, California 90064
Attention: Jeffrey Donfeld, Esq.
FAX: (310) 312 -8014
Either Party may, by notice given at any time, require subsequent notices to be given to
another person or entity, whether a Party or an officer or representative of a Party, or to
F-3
• • a
3
a different address, or both. Notices given before actual receipt of notice of change
shall not be invalidated by the change.
17. Severability. If any provision of this Agreement is determined by the final
judgment of a court of competent jurisdiction to be invalid or unenforceable, or if any
provision of this Agreement is superseded or rendered unenforceable according to any
law that becomes effective after the Effective Date, the remainder of this Agreement
shall be effective to the extent the remaining provisions are not rendered impractical to
perform, taking into consideration the purposes of this Agreement.
18. Time of Essence. Time is of the essence for each provision of this
Agreement of which time is an element.
19. Force Maieure /Enforced Delave Extension Of Time Of Performance. In
addition to specific provisions of this Agreement, performance by either Party hereunder
shall not be deemed to be in Default, and all performance and other dates specked in
this Agreement, including the Term, shall be extended, and all elements thereof where
delays or Defaults are due to: third party litigation (until a final, non - appealable judgment
has been obtained), or referendum or initiative challenging the validity of this
Agreement, the Existing Development Approvals, the Existing Land Use Regulations,
any Future Development Approvals, or any element thereof or the proceedings, acts, or
determinations taken, done or made prior to or related to such matters, or the right of
either Party to engage in the acts and transactions contemplated by this Agreement;
inability to secure necessary fuel, construction or labor materials, or tools; actions in
connection with the remediation of hazardous materials, including groundwater and soil
contamination; withdrawal of financing not caused by any act or omission of Developer,
war, insurrection; strikes; lockouts; riots; floods; earthquakes; fires; casualties; acts of
God; acts of the public enemy; acts of terrorism; epidemics; quarantine restrictions;
freight embargoes; lack of transportation; governmental restrictions or priority; building
moratoria; unusually severe weather; acts, delays, or omissions of the other Party; acts
or failures to act of the City or any other public or governmental agency or entity; or any
other causes beyond the control or without the fault of the Party claiming an extension
of time to perform ( "Enforced Delay"). The time for performance by a Party of its
obligations under this Agreement under any Enforced Delay shall be extended by a
number of days that is equal to the number of days that are caused by the delay,
including the number of days it takes to repair or restore the damage or reposition idled
contractors caused by any such Enforced Delay to the condition that existed prior to the
occurrence of the Enforced Delay (the "Delay Period ") provided that the Party asserting
a Delay Period has notified the other Party, in writing, within thirty (30) calendar days
following receipt of written notification by the Party of the Enforced Delay. In addition,
the Term, as extended, of this Agreement as set forth in Section 12 of this Agreement
shall be extended by any Delay Period. Times of performance under this Agreement
may also be extended in writing by the mutual agreement of the City and /or Developer.
20. Waiver. No waiver of any provision of this Agreement shall be effective
unless in writing and signed by a duly authorized representative of the Parry against
whom enforcement of a waiver is sought.
29
• 0 3
3
21. No Third Party Beneficiaries. This Agreement and all of its terms,
conditions, and provisions, is made and entered into for the sole protection and benefit
of the Developer and the City (and their respective successors and assigns), and not for
the benefit of any other individual or entity. No other person shall have any right of
action of any kind based upon any provision of this Agreement nor be deemed to be a
third party beneficiary under this Agreement.
22. Estoppel Certificates. Either Party hereunder may, at any time, deliver
written notice to the other Party requesting such Party to certify in writing that, to the
best knowledge of the certifying Party, (i) this Agreement is in full force and effect and a
binding obligation of the Parties, (ii) this Agreement has not been amended or modified,
or if so amended, identifying the amendments, and (iii) the requesting Party is not in
default in the performance of its obligations set forth in this Agreement or, if in default, to
describe therein the nature and amount of any such defaults. A Party receiving a
request hereunder shall execute and return such certificate within a reasonable time
following the receipt thereof. Developer shall pay City's reasonable costs, including
attorney fees, incurred in complying with this Section.
23. Attorneys' Fees. If any Party commences any action for the interpretation,
enforcement, termination, cancellation or rescission of this Agreement, or for specific
performance for the breach hereof, the prevailing Party shall be entitled to its
reasonable attorneys' fees, litigation expenses and costs arising from the action.
Attorneys' fees under this Section shall include attorneys' fees on any appeal as well as
any attorneys' fees incurred in any post - judgment proceedings to collect or enforce the
judgment.
24. Applicable Law. This Agreement shall be construed and enforced in
accordance with the laws of the State of California. Any legal action or proceeding
(other than any dispute heard pursuant to Section 13(b)) concerning this Agreement
shall be filed and prosecuted in the appropriate California state court in the County of
Los Angeles, California. Each Party hereto irrevocably consents to the personal
jurisdiction of that court. The Parties each hereby expressly waive the benefit of any
provision of federal or state law or judicial decision providing for the filing, removal, or
change of venue to any other court or jurisdiction, including, without implied limitation,
federal district court, due to any diversity of citizenship between the parties, due to the
fact that either or both of the Parties is a party to such action or proceeding or due to the
fact that a federal question or federal right is involved or alleged to be involved. Without
limiting the generality of the foregoing, the Parties each specifically waive any rights
provided to it pursuant to California Code of Civil Procedure Section 394. The Parties
acknowledge that the provisions of this paragraph are material consideration to the
Parties' entry into this Agreement, in that the Parties will avoid the potential cost,
expense and inconvenience of litigating in a distant forum.
25. Authority to Execute. The persons executing this Agreement warrant and
represent that they have the authority to execute this Agreement and represent that
they have the authority to bind the Parties for which they are signing to the performance
of the obligations hereunder. Developer represents and warrants to the City that it has
30
0 0
the power and authority to execute this Agreement and, once executed, this Agreement
shall be final, valid, binding and enforceable against Developer in accordance with its
terms. The City represents and warrants to Developer that (a) all public notices and
public hearings have been held in accordance with law and all required actions for the
adoption of this Agreement have been completed in accordance with applicable law; (b)
this Agreement, once executed by the City, shall be final, valid, binding and enforceable
against the City in accordance with its terms; and (c) this Agreement may not be
amended, modified, changed or terminated in the future by the City except in
accordance with the terms and conditions set forth herein.
26. Entire Agreement: Conflicts. This Agreement, including all Exhibits
attached hereto, represents the entire agreement of the Parties with respect to the
subject matter of this Agreement and this Agreement supersedes all previous
negotiations or agreements between the Parties or their predecessors in interest with
respect to all or any part of the subject matter hereof. Should any or all of the
provisions of this Agreement be found to be in conflict with any other provision or
provisions found in the Existing Land Use Regulations, the Existing Development
Approvals, or the Future Development Approvals, then the provisions of this Agreement
shall prevail.
27. City Approvals and Actions. Whenever a reference is made herein to an
action or approval to be undertaken by the City, the Director, or his or her designee is
authorized to act on behalf of City unless specifically provided otherwise or the context
should require otherwise.
28. Counterparts. This Agreement may be signed in multiple counterparts,
which, when signed by all Parties, shall constitute a binding agreement. This
Agreement is executed in two (2) originals, each of which is deemed to be an original.
29. Exhibits. The following documents are attached to, and by this reference
made a part of, this Agreement:
Exhibit "A" — Legal Descriptions of Entire Property and CE Zone.
Exhibit "B" — Maps of Entire Property and CE Zone.
Exhibit "C" — Site Plan showing Development of the Project.
Exhibit "D"— Schedule of Development Impact Fees.
Exhibit "E" — Annual Monitoring Report.
Exhibit "F" — Public Improvements to be Constructed and Dedicated
Exhibit "G" — Development Impact Fee Satisfaction List
30. Interpretation. As used in this Agreement, masculine, feminine or neuter
gender and the singular or plural number shall each be deemed to include the others
31
3A-
• • s
where and when the context so dictates. The word "including" shall be construed as if
followed by the words "without limitation." All section headings and subheadings are
inserted for convenience only and shall not affect any construction or interpretation of
this Agreement. This Agreement shall be interpreted as though prepared jointly by both
Parties.
31. Copies of Existing Land Use Regulations and Existing Development
Approvals. Prior to the Effective Date, the Parties shall prepare two (2) sets of the
Existing Land Use Regulations and Existing Development Approvals, one each for the
City and Developer, so that if it becomes necessary in the future to refer to any of the
Existing Land Use Regulations or Existing Development Approvals, there will be a
common set available to the Parties.
[SIGNATURES ON NEXT PAGE]
32
0
IN WITNESS WHEREOF, the Parties hereto have executed this Agreement as of
the date first written above.
CITY
CITY OF ARCADIA, CALIFORNIA
By:
William R. Kelly, City Manager
Date: 6A•pke
APPROVED AS TO FORM:
By: S� r
Step en P. Deitsch
City Attorney
ATTEST:
By: lieM I miyntL2
City Clek of the City of Ardadia
DEVELOPER
SAA
Santa Anita Associates, LLC,
a Delaware limited liability company
By: CARUSO
Santa Anita Associates Heldtmg Co., LLC,
a California limit y ny
By:
Print name: Rick J. Caruso
ffi. ...
33
3G
9
SACE
Santa Anita Commercial Enterprise, Inc.,
a Delaware corporatign,
Title:
Date:
By: 4
Title:
Date:
OWNER
The Santa Anita
a Cali
By: � a core
� f\
r ..
REM, �..
Inc.,
Title:
Date: C7
By:
rint Name: /+04"ee
Title: !/i-
Date: J
34
31
3�
EXHIBITS "A" AND "A-f
Legal Descriptions of Entire property and CE Zone
[attached as following page(s)]
p VpUBV BALLINGBR \728687.2
3
EXHIBIT A
RACE TRACK PROPERTY
ENTIRE PROPERTY
LEGAL DESCRIPTION
THE LAND REFERRED TO HEREIN IS SITUATED IN THE COUNTY OF LOS
ANGELES, STATE OF CALIFORNIA, AND IS DESCRIBED AS FOLLOWS:
THOSE PORTIONS OF LOTS 1 AND 5 OF TRACT 949, IN THE CITY OF
ARCADIA, AS SHOWN ON MAP RECORDED IN BOOK 17 PAGE 13 OF
MAPS, IN THE OFFICE OF THE COUNTY RECORDER OF SAID COUNTY,
DESCRIBED AS FOLLOWS:
BEGINNING AT THE SOUTHEAST CORNER OF PARCEL MAP NO. 4626, AS
SHOWN ON MAP FILED IN BOOK 51 PAGE 50 OF PARCEL MAPS, IN THE
OFFICE OF THE COUNTY RECORDER OF SAID COUNTY, BEING A POINT
ON THE NORTH LINE OF HUNTINGTON DRIVE, 195.00 FEET IN WIDTH;
THENCE ALONG THE EASTERLY AND NORTHEASTERLY BOUNDARY OF
SAID PARCEL MAP AS FOLLOWS:
NORTH 3 053'00" EAST 475.68 FEET TO THE BEGINNING OF A TANGENT
CURVE CONCAVE TO THE EAST AND HAVING A RADIUS OF 1200.00 FEET;
THENCE NORTHERLY ALONG SAID CURVE THROUGH A CENTRAL ANGLE
OF 15 031'48" AN ARC DISTANCE OF 325.26 FEET; THENCE TANGENT TO
SAID CURVE NORTH 19 024'48" EAST 534.43 FEET TO THE BEGINNING OF
A TANGENT CURVE CONCAVE TO THE WEST AND HAVING A RADIUS OF
350,00 FEET; THENCE NORTHERLY AND NORTHWESTERLY ALONG SAID
CURVE THROUGH A CENTRAL ANGLE OF 71022480 AN ARC DISTANCE OF
436.03 FEET; THENCE TANGENT TO SAID CURVE NORTH 51 °58'00" WEST
873.36 FEET; THENCE CONTINUING ALONG SAID BOUNDARY OF PARCEL
MAP NO. 4626 NORTH 66 058'00" WEST 154.55 FEET AND NORTH 51 058'00"
WEST 437.83 FEET TO THE MOST NORTHERLY CORNER OF SAID PARCEL
MAP, BEING A POINT ON THE SOUTHEASTERLY LINE OF BALDWIN
.AVENUE, 100.00 FEET IN WIDTH, THENCE NORTHEASTERLY ALONG SAID
SOUTHEASTERLY LINE OF BALDWIN AVENUE, AS IT NOW EXISTS, TO THE
INTERSECTION WITH THE WESTERLY PROLONGATION OF THE
SOUTHERLY BOUNDARY LINE OF TRACT 15318 AS SHOWN ON MAP
RECORDED IN BOOK 427 PAGES 34 AND 35 OF SAID MAPS, SHOWN
THEREON AS HAVING A BEARING OF NORTH 88 057'33" EAST; THENCE
NORTH 86 057'33" EAST ALONG SAID SOUTHERLY BOUNDARY LINE TO
THE ANGLE POINT IN THE SOUTHERLY LINE OF LOT 38 OF SAID TRACT
15318; THENCE CONTINUING ALONG THE BOUNDARY LINE OF SAID
TRACT 15318, AND THE SOUTHERLY BOUNDARY LINE OF TRACT 14940
AS SHOWN ON MAP RECORDED IN BOOK 350 PAGES 48 TO 50 INCLUSIVE
OF SAID MAPS, NORTH 68 °46'53" EAST 2265.62 FEET TO THE MOST
EASTERLY CORNER OF LOT 81 OF SAID TRACT 14940, BEING A POINT ON
THE SOUTHWESTERLY LINE OF COLORADO PLACE; THENCE SOUTH
30 033'16" EAST 2171.20 FEET ALONG SAID SOUTHWEST LINE OF
COLORADO PLACE, 80.00 FEET IN WIDTH, AS IT NOW EXISTS, TO THE
BEGINNING OF TANGENT CURVE THEREIN, CONCAVE TO THE
NORTHEAST AND HAVING A RADIUS OF 756.78 FEET; THENCE
SOUTHEASTERLY ALONG SAID CURVE 554.82 FEET TO THE
INTERSECTION WITH THE CURVED NORTHWESTERLY LINE OF
HUNTINGTON DRIVE, 80.00 FEET IN WIDTH, SAID CURVE BEING
CONCAVE TO THE SOUTHEAST HAVING A RADIUS OF 995.37 FEET;
THENCE SOUTHWESTERLY ALONG SAID CURVE 607.48 FEET; THENCE
SOUTHWESTERLY ALONG THE NORTHWESTERLY LINE OF SAID
HUNTINGTON DRIVE, AS IT NOW EXISTS, 2843.30 FEET TO THE
BEGINNING OF A TANGENT .CURVE THEREIN CONCAVE TO THE
NORTHWEST AND HAVING A RADIUS OF 915.20 FEET; THENCE
SOUTHWESTERLY AND WESTERLY ALONG SAID CURVE 883.99 FEET;
THENCE WESTERLY ALONG THE NORTHERLY LINE OF SAID
HUNTINGTON DRIVE, AS IT NOW EXISTS TO THE POINT OF BEGINNING.
TOGETHER WITH PARCEL 4 OF PARCEL MAP NO. 4626, AS SHOWN ON
MAP RECORDED IN BOOK 51, PAGE 50 OF PARCEL MAPS, IN THE OFFICE
OF THE COUNTY RECORDER OF SAID COUNTY
EXCEPT THEREFROM THAT PORTION OF SAID LAND LYING WITHIN
PARCEL 1 OF PARCEL MAP NO. 15852, IN THE CITY OF ARCADIA, AS PER
MAP FILED IN BOOK 179 PAGES 93 AND 94 OF PARCEL MAPS, IN THE
OFFICE OF THE COUNTY RECORDER OF SAID COUNTY.
ALSO EXCEPT THEREFROM THOSE PORTIONS OF THE ABOVE
DESCRIBED PARCEL LYING WITHIN PARCELS 3 AND 4 OF PARCEL MAP
NO. 23862, IN THE CITY OF ARCADIA, AS PER MAP FILED IN BOOK 261
PAGES 91 THROUGH 95 INCLUSIVE OF PARCEL MAPS, IN THE OFFICE OF
THE COUNTY RECORDER OF SAID COUNTY.
SAID PARCELS ARE SHOWN ON EXHIBIT "A" ATTACHED HERETO AND BY THIS
REFERENCE MADE A PART HEREOF.
e
W
/ T ( MERCADO\
�PLS, 3�7� * Ez NOt 26382 DB
PATRICK R. ERCA S 6382 sfq
EXHIBIT A -1
COMMERCIAL ENTERTAINMENT ZONE
PROPERTY
LEGAL DESCRIPTION
THE LAND REFERRED TO HEREIN IS SITUATED IN THE COUNTY OF LOS
ANGELES, STATE OF CALIFORNIA, AND IS DESCRIBED AS FOLLOWS:
THOSE PORTIONS OF LOTS 1 AND 5 OF TRACT 949, IN THE CITY OF
ARCADIA, AS SHOWN ON MAP RECORDED IN BOOK 17 PAGE 13 OF
MAPS, IN THE OFFICE OF THE COUNTY RECORDER OF SAID COUNTY,
DESCRIBED AS FOLLOWS:
BEGINNING AT THE SOUTHEAST CORNER OF PARCEL MAP NO. 4626, AS
SHOWN ON MAP FILED IN BOOK 51 PAGE 50 OF PARCEL MAPS, IN THE
OFFICE OF THE COUNTY RECORDER OF SAID COUNTY, BEING A POINT
ON THE NORTH LINE OF HUNTINGTON DRIVE, 195.00 FEET IN WIDTH;
THENCE ALONG THE EASTERLY AND NORTHEASTERLY BOUNDARY OF
SAID PARCEL MAP AS FOLLOWS:
NORTH 3 053'00" EAST 475.68 FEET TO THE BEGINNING OF A TANGENT
CURVE CONCAVE TO THE EAST AND HAVING A RADIUS OF 1200.00 FEET;
THENCE NORTHERLY ALONG SAID CURVE THROUGH A CENTRAL ANGLE
OF 15 031'48" AN ARC DISTANCE OF 325.26 FEET; THENCE TANGENT TO
SAID CURVE NORTH 19 02448" EAST 534.43 FEET TO THE BEGINNING OF
A TANGENT CURVE CONCAVE TO THE WEST AND HAVING A RADIUS OF
350.00 FEET; THENCE NORTHERLY AND NORTHWESTERLY ALONG SAID
CURVE THROUGH A CENTRAL ANGLE OF 71 022'48" AN ARC DISTANCE OF
436.03 FEET; THENCE TANGENT TO SAID CURVE NORTH 51 °58'00" WEST
873.36 FEET; THENCE CONTINUING ALONG SAID BOUNDARY OF PARCEL
MAP NO. 4626 NORTH 66 °58'00" WEST 154.55 FEET; THENCE NORTH
53 °00'43" WEST 42.12 FEET TO THE BEGINNING OF A NON - TANGENT
CURVE CONCAVE NORTHWESTERLY HAVING A RADIUS OF 90.00 FEET,
THROUGH WHICH POINT A RADIAL LINE BEARS NORTH 53 000'43" WEST,
THENCE EASTERLY AND NORTHEASTERLY ALONG SAID CURVE
THROUGH A CENTRAL ANGLE OF 42 °09'04" AN ARC DISTANCE OF 66.21
FEET TO THE BEGINNING OF A REVERSING CURVE CONCAVE
SOUTHEASTERLY HAVING A RADIUS OF 169.00 FEET, THROUGH WHICH
POINT A RADIAL LINE BEARS NORTH 30 024'38" WEST, THENCE
NORTHEASTERLY AND EASTERLY ALONG SAID CURVE THROUGH A
CENTRAL ANGLE OF 84 °29'41" AN ARC DISTANCE OF 249.23 FEET;
THENCE SOUTH 35 054'57" EAST 134.95 FEET TO THE BEGINNING OF A
TANGENT CURVE CONCAVE NORTHERLY AND HAVING A RADIUS OF
481.00 FEET; THENCE SOUTHEASTERLY ALONG SAID CURVE THROUGH
0
A CENTRAL ANGLE OF 16°40'55" AN ARC DISTANCE OF 140.05 FEET;
THENCE TANGENT TO SAID CURVE SOUTH 52 035'52" WEST 150.00 FEET;
THENCE SOUTH 55 013'59" EAST 142.20 FEET TO THE BEGINNING OF A
TANGENT CURVE CONCAVE NORTHEASTERLY AND HAVING A RADIUS
OF 300.00 FEET; THENCE SOUTHEASTERLY AND EASTERLY ALONG SAID
CURVE THROUGH A CENTRAL ANGLE OF 28 038'52" AN ARC DISTANCE OF
150.00 FEET; THENCE TANGENT TO SAID CURVE SOUTH 83 052'52" WEST
32.57 FEET; THENCE SOUTH 87 125'14" WEST 171.59 FEET TO THE
BEGINNING OF A TANGENT CURVE CONCAVE TO THE NORTHWEST. AND
HAVING A RADIUS OF 25.00 FEET; THENCE EASTERLY AND
NORTHEASTERLY ALONG SAID CURVE THROUGH A CENTRAL ANGLE OF
51 007'50" AN ARC DISTANCE OF 22.31 FEET TO THE BEGINNING OF A
REVERSING CURVE CONCAVE SOUTHEASTERLY HAVING A RADIUS OF
115.00 FEET, THROUGH WHICH POINT A RADIAL LINE BEARS NORTH
48 033'04" WEST, THENCE NORTHEASTERLY AND EASTERLY ALONG SAID
CURVE THROUGH A CENTRAL ANGLE OF 48 °24'24" AN ARC DISTANCE OF
97.16 FEET; THENCE SOUTH, 89 051'19" WEST 6.06 FEET TO THE
BEGINNING OF A TANGENT CURVE CONCAVE NORTHWESTERLY AND
HAVING A RADIUS OF 50.00 FEET; THENCE NORTHEASTERLY ALONG
SAID CURVE THROUGH A CENTRAL ANGLE OF 85 057'34" AN ARC
DISTANCE OF 75.01 FEET; THENCE NORTH 03 053'45" EAST 292.68 FEET;
THENCE SOUTH 87 047'13" EAST 653.26 FEET THENCE SOUTH 73 009'27"
EAST 563.47 FEET; THENCE NORTH 16 050'33" EAST 38.22 FEET ;; THENCE
SOUTH 73 009'27" EAST 36.78 FEET; THENCE NORTH 16 "50'33° EAST 155.14_
FEET; THENCE SOUTH 73 009'27" EAST 521.61 FEET; THENCE SOUTH
52 027'43" EAST 424.98 FEET TO THE NORTHWESTERLY LINE OF
HUNTINGTON DRIVE 80.00 FEET WIDE; THENCE SOUTHWESTERLY
ALONG THE NORTHWESTERLY LINE OF SAID HUNTINGTON DRIVE, AS IT
NOW EXISTS, 1,831.93 FEET TO THE BEGINNING OF A TANGENT CURVE
THEREIN CONCAVE TO THE NORTHWEST AND HAVING A RADIUS OF
915.20 FEET; THENCE SOUTHWESTERLY AND WESTERLY ALONG SAID
CURVE 883.99 FEET; THENCE WESTERLY ALONG THE NORTHERLY LINE
OF SAID HUNTINGTON DRIVE, AS IT NOW EXISTS TO THE POINT OF
BEGINNING.
TOGETHER WITH PARCEL 4 OF PARCEL MAP NO. 4626, AS SHOWN ON
MAP RECORDED IN BOOK 51, PAGE 50 OF PARCEL MAPS, IN THE OFFICE
OF THE COUNTY RECORDER OF SAID COUNTY
EXCEPT THEREFROM THAT PORTION OF SAID LAND LYING WITHIN
PARCEL 1 OF PARCEL MAP NO. 15852, IN THE CITY OF ARCADIA, AS PER
MAP FILED IN BOOK 179 PAGES 93 AND 94 OF PARCEL MAPS, IN THE
OFFICE OF THE COUNTY RECORDER OF SAID COUNTY.
ALSO EXCEPT THEREFROM THOSE PORTIONS OF THE ABOVE
DESCRIBED PARCEL LYING WITHIN PARCELS 3 AND 4 OF PARCEL MAP
NO, 23862, IN THE CITY OF ARCADIA, AS PER MAP FILED IN BOOK 261
PAGES 91 THROUGH 95 INCLUSIVE OF PARCEL MAPS, IN THE OFFICE OF
THE COUNTY RECORDER OF SAID COUNTY.
SAID PARCELS ARE SHOWN ON EXHIBIT "B -1" ATTACHED HERETO AND BY THIS
REFERENCE MADE A PART HEREOF.
PATRICK
RAY
MERCADO
c.. 3 -%Q7 ((*Exp. 12/31/06
N0. 6382
2 rq, �s
EXHIBITS WAND " &1"
Maps of Entire Property and CE Zone
(attached as following page(s)]
RVPUBUBALLINGERV28683.2
9 0
XW�
iwrc 4
r2aa L Ea
� p
d 6E G�h3
e� N
�IiA I 7 Y�v9
EYEY
vd
J 1 n
/ HY
AF e 15 &
13 &/
s
pP YY
G
2 9
p i 1
edP d
3 @Qa i� / ■5(�1 � � �e;3 Anotva ��
as
1 d pPH tt b
D \Q.
o'
K ��• !Pl
d o"
!e
• •
0-1
EXHIBIT "C'
Site Plan
[attached as following page(s)]
RV PUBVBALLINOBR\72B6&3.2
U
0
0
EXHIBIT "D"
Schedule of Development Impact Fees
The only Development Impact Fee that applies to the Project is the City's Traffic Impact
Fee. The Traffic Impact Fee schedule is provided below:
Land Use
PM Peak Hour
Trips
Cost Per Unit
General Retail
3.75 / KSF
$ 5.851 SQ FT
Restaurant
7.491 KSF
$11.68 ! SQ FT
Fast Food Restaurant
1 17.32 / KSF'
I $27x2 / SQ FT
Supermarket
7.32 / KSF"
$11.42 ! SQ FT
General Office
1.491 KSF
$ 2.32 / SQ FT
The Park and Recreation Facilities Fee only applies to residential projects and therefore
is not applicable to this Project. The City has no other Development Impact Fees at the
time of the Effective Date of this Agreement.
R V P UB V BALLING ER \728683.2
0
R V PUBVBALLIN08R \728683.2
EXHIBIT "E"
Annual Monitoring Report
[attached as following page(s)]
Development Agreement
Annual Monitoring Report
PROJECT PROPONENT INFORMATION (print or type)
Applicant's Primary Contact:
Address:
Telephone No.:
Applicant's Additional Contact (optional):
Address
Telephone No.:
Fax No.:
Fax No.:
DEVELOPMENTAGREEMENT INFORMATION
Development Agreement
No.:
(For staff use only)
File Na:
Related Flies:
Submittal Date:
Rec'd By:
Fee Paid: $
Date of Original Development
Agreement:
(Month, Day, Year)
Name of Party/Parties (Other than
City) Subject to the Development
Agreement:
Date of Last
Review:
Day,
DEVELOPMENT AGREEMENT STATUS
PLEASE COMPLETE THE FOLLOWING QUESTIONS. ATTACH ADDITIONAL SHEETS IF
NECESSARY.
Has the Development Agreement been assigned to any other Party not listed above? If yes, who has the
Development Agreement been assigned to and when did the assignment occur?
R VPUBV BALLINGER5728683.2
Cfty of Arcakla
�.'
Development Services
Post Office Box 60021
Ancadia, CA 91006
, «Phone:
(626) 574 -5423
�
Fax: (626) 447-9173
Development Agreement
Annual Monitoring Report
PROJECT PROPONENT INFORMATION (print or type)
Applicant's Primary Contact:
Address:
Telephone No.:
Applicant's Additional Contact (optional):
Address
Telephone No.:
Fax No.:
Fax No.:
DEVELOPMENTAGREEMENT INFORMATION
Development Agreement
No.:
(For staff use only)
File Na:
Related Flies:
Submittal Date:
Rec'd By:
Fee Paid: $
Date of Original Development
Agreement:
(Month, Day, Year)
Name of Party/Parties (Other than
City) Subject to the Development
Agreement:
Date of Last
Review:
Day,
DEVELOPMENT AGREEMENT STATUS
PLEASE COMPLETE THE FOLLOWING QUESTIONS. ATTACH ADDITIONAL SHEETS IF
NECESSARY.
Has the Development Agreement been assigned to any other Party not listed above? If yes, who has the
Development Agreement been assigned to and when did the assignment occur?
R VPUBV BALLINGER5728683.2
Describe the current nature of proponent's project.
the size of the project, where the project is locate d
should take the proponent to complete development
scope, timing of the project.
RV PUBVBALLINaERW28683.2
The description should include a brief explanation of
, what the proponent Intends to build, how long It
of the project, and any changes In the nature, type,
What development has occurred since the last review (either special or annual)? Include the entitlements
that have been issued to date, including, discretionary entitlements, including architectural review,
subdivisions, variances, etc., as well as ministerial permits, including, grading permits, building permits,
certificates of occupancy that have been issued for the project. Include the percentage, if any, of the
project that is completed and the percentage, if any, actually occupied. If any development has not
occurred that was required or expected to occur, provide an explanation of why such development has
not yet occurred.
Please list all development exactions, dedications, development impact fees and public improvements that
the developer has provided in connection with the project since the last review.
Please describe any outstanding obligations of developer. Please provide a detailed explanation of why
the proponent has not met an obligation and when total compliance is contemplated. If there are any
Impediments that have prevented the project proponent from complying with the terms of the
Development Agreement, please explain.
Y
RVPUBV BALLINCER1728683.2
Please provide, in detail, any periods of delay in performance by developer that developer believes are
subject to any force majeure/enforced delay provisions of the development agreement. This list shall be
cumulative of all such force majeure/ enforced delays since the adoption of the development agreement.'`
CERTIFICATION
I, , certify that I have used all reasonable
diligence in preparing this report. I have reviewed all the information in the report and I certify that all
information contained herein is true and correct.
Date
Signed
Year)
Signature
Additional Comments/ Notes by developer /applicant:
RV PUBVBA LLINGER \728683.2
EXHIBIT T"
Public Improvements to be Constructed and Dedicated
Bus Stop Locations - Currently, the MTA has four bus stops near the perimeter of
the project site, located at Huntington Drive and Baldwin Avenue, Huntington
Drive and La Cadena Avenue, Huntington Drive and Holly Avenue and Huntington
Drive West and Centennial Way. Relocation of existing bus stops and the
provision of additional bus stops should be considered to accommodate transit
users at convenient locations, including possible new stops that would be internal
to the site.
■ Restripe /reconstruct eastbound off -ramp to provide one shared through -left lane
and one exclusive left turn only lane and one right turn lane that could allow right
turns. Free cant' extra southbound lane along Baldwin Avenue to Gate 8.
(Baldwin Avenue and 1 -210 Eastbound Ramps [partially controlled by Caltrans])
■ Restripe the westbound approach lanes to provide dual right turn lane and a
shared through left turn lane (north bound right turn lane). Extend southbound left
turn pocket 200 feet farther to the north to accommodate left turning queues.
(Baldwin Avenue and Gate 8) Also, install fiber optic cable /conduit.
■ Restripe /reconstruct northbound approach to provide an exclusive right turn lane.
Reconstruct to provide dual north and south bound left turn lanes. (Rosemead
Boulevard and Huntington Drive [County of L.A.])
• Restripe /reconstruct to provide eastbound and westbound dual left turn lanes.
(Baldwin Avenue and Duarte Road) Also, install video detection /CCTV camera
and a traffic monitoring station.
• Add a second northbound left turn lane northbound. (Baldwin Avenue and
Huntington Drive) Also, install video detection /CCTV camera and a
communications hub.
■ Restripe /reconstruct approach (between the two one -way legs of Huntington Drive
and Campus Drive) to provide left lane, shared through left lane and an additional
northbound through lane. Restripe /reconstruct westbound approach to provide an
exclusive right turn lane. Reconstruct southbound at Gate 3 to provide three
through lanes and an exclusive right turn lane. (Holly Avenue —Gate 3 and
Huntington Drive) Also, install a video detection /CCTV camera and a traffic
monitoring system.
Modify track parking entrance to Colorado Place, providing additional storage
capacity, and route track ingress traffic to the north. Implement race -day traffic
RV PUBVBALLINGER \728683.2
control. Restripe /reconstruct westbound movement to provide additional third
through lane on Huntington Drive to the southwest direction. (West Colorado
Place and Huntington Drive) Also, install video detection /CCTV camera.
■ Widen northbound approach to provide one left turn lane, two through lanes, two
right turn lanes. Restripe /reconstruct westbound approach to provide three
through lanes. (Santa Clara Street and Huntington Drive) Also, install a
communications hub.
• Reconstruct to provide dual northbound and southbound left turn lanes. (Santa
Anita Avenue and Huntington Drive) Also, install a communications hub.
■ Restripe /reconstruct to provide a northbound exclusive right turn lane.
Restripe /reconstruct to provide dual left turn lanes eastbound, one through lane
and one right turn lane, modify signal phasing. (Santa Anita Avenue and Santa
Clara Street) Also, install a communications hub.
• Install traffic signal. (Centennial Way and Huntington Drive West) Also, install fiber
optic cable /conduit.
• Install traffic signal. Also widen to provide northbound exclusive left turn lane in
addition to existing three through lanes. (Centennial Way and Huntington Drive
East)
■ Change northbound /southbound phasing to permitted phasing.
Restripe /reconstruct NB and SB lanes to provide one left turn lane, one through
lane and one shared through -right lane. Restripe northbound lanes to provide
right turn only lane. (Sunset Boulevard and Huntington Drive). Also, install fiber
optic cable /conduit.
■ Reconstruct to provide dual southbound left turn lanes, and eastbound right turn
only lane. (Santa Anita Avenue and Duarte Road) Also, install a video
detection /CCTV camera and a traffic monitoring system.
■ Re- stripe /reconstruct to add dual left turn lanes to northbound, southbound, and
westbound approaches. (Santa Anita Avenue and Foothill Boulevard) Also, install
fiber optic cable /conduit, a video detection /CCTV camera, and a traffic monitoring
station.
• Restripe /reconstruct southbound approach to provide one left turn lane, one
through lane and one shared through -right lane. (Michillinda Avenue and
Colorado Street [partially controlled by County of L.AJ)
• Restripe /reconstruct to provide northbound and southbound right turn only lanes.
(Duarte Road at Rosemead Boulevard [County of L.A.])
RV PUBUBALLINGEM72868J.2
Add overlap phase for northbound right turn. (San Gabriel Boulevard and
Huntington Drive [County of L.A. and San Marino])
■ Re- stripe /reconstruct to provide eastbound right -tum -only lane and eastbound
dual - left-tum lanes. (Sierra Madre and Huntington Drive [San Marino])
■ The Developer shall post a bond in the amount of $300,000 to fund potential
neighborhood traffic improvements for the locations identified under
Impacts 4.13 -4 and 4.13 -12 that may be subject to potentially significant
neighborhood impacts. It is anticipated that this amount shall be sufficient to
implement one or more of the following measures to make local routes less
attractive to through traffic: turn restrictions, chokers or narrowing of street widths,
diverters or semi - diverters, cul -de -sacs or street closures, stop signs or other
measures approved by the Development Services Director. Further, it is
anticipated that this amount shall be sufficient to implement one or more of the
following parking restrictions in conjunction with the affected residents on the
streets impacted by parking or traffic intrusion. These measures may include, but
are not limited to, the following:
1. Posting of parking restrictions in the residential neighborhoods on these
streets or other streets that might be affected (such as parking for 1 hour only on
street or no parking at certain times)
2. Implementation of permit parking district(s) in the residential
neighborhoods (allowing only residents or guests or both to park on street with a
permit)
The neighborhood traffic control program will include outreach to and participation
by all affected residents, with affected residents voting on the program elements
and with a required 60 percent approval. The approved program then would be
submitted to the City's Traffic Advisory Committee and then to City Council for
final approval.
• Construction of sidewalk, handicapped ramps and concrete pads for pedestrians
at bus stops along perimeter of property along Huntington Drive.
■ Construction of improvements in public right -of -way at Gate 8.
RV PUBV BALLINGER1728681.2
0
EXHIBIT "G"
Development Impact Fee Satisfaction List
Developer is required to construct and dedicate certain public improvements as
described in Exhibit F to this Development Agreement. Many of these improvements in
Exhibit F pertain to traffic improvements. Pursuant to the City of Arcadia adopted
Transportation Master Plan and Traffic Impact fee program, for Developer constructed
traffic improvements listed in the Transportation Master Plan, Developer will receive a
credit against the applicable Development Impact Fee based on the cost of these
improvements. The actual amount of the Development Impact Fee to be satisfied is
dependent on the ultimate size in square footage of the Project and the actual costs of
the public improvements listed in the Transportation Master Plan that are constructed by
Developer.
RVPUBUBALL[NGERV 28683.2
0
CALIFORNIA ALL - PURPOSE ACKNOWLEDGMENT
0 (0()
STATE OF STATE )
ss.
COUNTY OF LOS ANGELES )
On `I1 Lg 2 , .2007
before m , y v E1T5i NOS 6 e kN , u orA &,
.4 P
Dab Nerve ME Tft Of Ofnwr Ia.a.'Jans Doe. N q Pudb')
personally appeared 2,i CXn J G A /u'{ S o
Name of Signer(.)
$( personally known to me — OR — proved to me on the basis of satisfactory evidence to be the
personal whose name(sy is /ara subscribed to the within
instrument and acknowledged to me that he /sheAMre -
executed the same in his /ha#4he4r- authorized capacity(ies),
and that by his/her /their signature(s) on the instrument the
YyElMOSE"4w person(s), or the entity upon behalf of which the person(s)
Cofnmladon • 1424682
Notary PubBc•Calfa to acted, executed the instrument.
Los Arown county QMV Conan . Explm Jul 12,2W7 WITNESS myuhand and official seal.
�r
OPTIONAL
Though the data below is not required by law, it may prove valuable to persons relying on the document and could
prevent fraudulent reattachment of this form.
CAPACITY CLAIMED BY SIGNER
❑ Individual
❑ Corporate Officer
Tifle(s)
❑ Partner(s) ❑ Limited
❑ General
❑ Attorney -In -Fact
❑ Trustee(s)
❑ Guardian /Conservator
❑ Other:
Signer is representing:
Name Of Person(s) Or Entity(ies)
RVPUBV BALLINGER1728687.2
DESCRIPTION OF ATTACHED DOCUMENT
Title or Type of Document
Title or Type of Document
Number Of Pages
Date Of Document
Signers) Other Than Named Above
CALIFORNIA ALL - PURPOSE ACKNOWLEDGMENT
STATE OF STATE )
ss.
COUNTY OF LOS ANGELES )
• 0
On `h ta, , 130 .2007
before me, Moat -y M, R0BB1A)5, Nara,ey Auaur.
Dab Name And Title Of Officer (e.g. 'Jane Doe, Notary Pubbe)
personally appeared FZA,Je DE mA,acn !Z?
Name N Stnerfe)
0 personally known to me — OR — 0
proved to me on the basis
person($) whose name(p
instrument and acknowl
Factory evidence to be the
subscribed to a within
to me that he
executed the me in is 'r authorized capacity(is&),
and that by hi r signature(o) on the
person($), or the entity upon behalf of which
acted, executed the instrument.
WITNESS my hand and official seal.
OPTIONAL
instrument the
the person()
Though the data below is not required by law, it may prove valuable to persons relying on the document and could
prevent fraudulent reattachment of this form.
CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT
❑ Individual
Of Corporate Officer
a _to . 8- Gaac� tam Szcf c.trn y a , ZZW �
'rifle eoYDocument
Ti e(s} Title or Type of Document
❑ Partner(s) ❑ Limited
❑ General
❑ Attorney -In -Fact
❑ Trustee(s)
❑ Guardian /Conservator
❑ Other:
y (FIFTY- ElGNT�
Number Of Pages
Date Of Document
Signer is representing:
Name Of Person(s) Or En6tty(les),
Sigrier(s) Other Than Named ADOVe
Qh C'adCRi`�[.L y `�zLr�tki
R V pUBVBALLINGERV 28683.2
'CALIFORNIA ALL-PURPOSE
STATE OF STATE )
ss.
COUNTY OF LOS ANGELES )
0
On .',nn.4 so 2007
before me, MOLLY M _ NnTAZV PUSC40 — ,
Dam Nam N Tale Of OMaar (e.g. 'Jana Doe, Notary Pubikn
personally appeared FeAmi—, DE MAP-co, 2 ,
Nam of Signed,)
0 personally known to me — OR — 9
;;/nor; \„ '77711113 i;
proved to me on the basis of satisfactory evidence to be the
person() whose name(, is ace subscribed to he within
instrument and ackno ledged to me that he shefthey
executed the aamh e iii s herftheif authorized capacity(ies),
and that by i signature(s) on the instrument the
person($), or the entity upon behalf of which the person($)
acted, executed the instrument.
WITNESS my hand and official seal.
OPTIONAL
Though the data below is not required by law, it may prove valuable to persons relying on the document and could
prevent fraudulent reattachment of this form.
CAPACITY CLAIMED BY SIGNER
❑ Individual
J� Corporate Officer
Titles)
❑ Partner(s) ❑ Limited
❑ General
❑ Attorney -In -Fact
❑ Trustee(s)
❑ Guardian /Conservator
❑ Other:
Signer is representing:
Name Of Person(s) Or Entlty(ies).
Sa w "ta, alu P- YQAi wxt ko .
RV PUBV BALLINGER1728683.2
DESCRIPTION OF ATTACHED DOCUMENT
,Qeu�Gc7EZar -en.� �uvi,LVr�G
Title or Type of Document
or Type of Document
5V7 (FtFFV -er(,- La)
Number Of Pages
Date Of Document
A4lC /�i0 ' � b i4 A/ Y�/t 2t�in i
Signer(s) Other Than Named boys
OneacGca. `&.sty `d lv, *E
CALIFORNIA ALL - PURPOSE ACKNOWLEDGMENT
STATE OF STATE )
ss.
COUNTY OF LOS ANGELES )
On 2007
before m4, MQL L-V Al RQZVR /.il5 NOTHRY Yagi -1 '
Deft Name AM Tide Of Oaker (e.g. 'Jam low, Notary Public')
personally appeared kON c14,g&Li =s
Name of Slants)
personally known to me — OR — ❑D proved to me on the basis of atisfactory evidence to be the
person(, whose name( is subscribed to the within
instrument and ackngmodged to me that he
executed the me in his erfiheir authorized capaclty(ies),
and that by is slgnature(4 on the instrument the
person(g), or the entity upon behalf of which the person(s)
MOLLY M.ROBW acted, executed the instrument.
ConarMplon � 1691 Z01
aitptr cameo _ WITNESS my hand and official seal. 1, OWN COU*
1grcoern. boom Adto. Zi
a rt,
gnature o 0 c
OPTIONAL
Though the data below is not required by law, it may prove valuable to persons relying on the document and could
prevent fraudulent reattachment of this form.
CAPACITY CLAIMED BY SIGNER
❑ Individual
09 Corporate Officer
0 ... •
❑ Partner(s) ❑ Limited
❑ General
❑ Attorney -In -Fact
❑ Trustee(e)
❑ Guardian /Conservator
❑ Other:
Signer is representing:
Name Of Person(s) Or Entity(les)
J Mr�R Q.wi�tl. �o4- rn„mi.t i >,tii /, tn^ =iat�,
RV PUBV BALLINGEM728683.2
DESCRIPTION OF ATTACHED DOCUMENT
bt�t.e_r t Q¢,�c'rx.vtt
Tltte or Type of Document
Title or Type of Document
SS (Fi rTV-E IGHT)
Number Of Pages
10M
Of Document
Slgner(s) Other, Than Named Above
CzAefcaGca �<tiy Palc,ki
CALIFORNIA ALL - PURPOSE ACKNOWLEDGMENT
STATE OF STATE )
SS.
COUNTY OF LOS ANGELES )
On .2007
before me, MOt_Lvm knLga,&)s A/&rAQy
Deb Nmne Mtl Title Or Oec<r (e.g. 'Jane Doe, Notary nubile)
personally appeared RQfJ CNAetfs
Name of Slgmr(s)
personally known to me — OR — xO proved to me on the basis of satisfactory evidence to be the
person(, ) whose name(>{j is/ subscribed to a within
instrument and ackn dged to me that he
executed the mein is authorized capacity(ies),
and that by is signature(,t;) on the instrument the
M. person(f, or the entity upon behalf of which the person(s)
c ,,#1591201 acted, executed the instrument.
Notary Kdm - camondo
a11Ano .carat' WITNESS my hand and official seal.
Ma zo, 20
Signature o Wary Public
OPTIONAL
Though the data below Is not required by law, it may prove valuable to persons relying on the document and could
prevent fraudulent reattachment of this form.
CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT
❑ Individual
0 Corporate Officer'� DD �icz Gap rn n ^�
VA,,t.b ,Tcr.%n,n..,., rn.0 r,,,r O Title or Type of Document
Tides) Title or Type of Document
❑ Partner(s) ❑ Limited
❑ General
❑ Attorney -In -Fact
❑ Trustee(s)
❑ Guardian /Conservator
❑ Other.
Signer is representing:
Name Of Person(s) Or Endty(iss)
R V PUBUBALLINGEM728683.2
S$ (_Firr l- E IQa r)
Number Of Pages
—G'
Date Of Document
�lr�LCt -, .Q[,i f r�.Ciil �oG7.t.i�� �P�fYVit nn
^ Sign�er1s) Other Than Named Above
wLCRGLCA/ �l.(N('�a�(hIEJ
CALIFORNIA ALL - PURPOSE ACKNOWLEDGMENT
STATE OF STATE )
ss.
COUNTY OF LOS ANGELES )
On
bef(
personally appeared
pt personally known to me — OR — ❑O
laUSAMNs
Cennnlwee • 117117=
LrNq le Courdit,
lulfcanw=AW7.2011
proved to me on the basis of satisfactory evidence to be the
person(aj whose name(( i are subscribed t the within
instrument and acknowledged to me that khq sge/ttasy
executed the same in hi /Her/t & authorized capaclty�ea ,
and that by his signature(lil on the instrument the
personJe�"or he entity upon behalf of which the personfsf
acted, executed the instrument.
my tond and official seal.
OPTIONAL
Though the data below is not required by law, it may prove valuable to persons relying on the document and could
prevent fraudulent reattachment of this form.
CAPACITY CLAIMED BY SIGNER
❑ Individual
❑ Corporate Officer
Title(s)
❑ Partner(s) ❑ Limited
❑ General
❑ Attomey -In -Fact
❑ Trustee(s)
❑ Guardian /Conservator
❑ Other:
Signer is representing:
Name Of Person(s) Or EnBty(les)
RV PUBVBALLINGER \728683.2
DESCRIPTION OF ATTACHED DOCUMENT
Title or Type of Document
Title or Type of Document
Number Of Pages
Date Of Document
Signer(s) Other Than Named Above