HomeMy WebLinkAboutC-297111
1j
1.1
i
1
I10.
ARCADIA
3i� (-�pls-
OR1�INAL
2014 C 2015 ANNUAL SLURRY SEAL PROJECT
PROJECT No: 55331015
BID AND CONTRACT DOCUMENTS
TOM TAIT
PUBLIC WORKS SERVICES DIRECTOR
PHILIP A. WRAY
CITY ENGINEER
1100 -VCS
e -zqli
SCHEDULED BID OPENING: TUESDAY, APRIL 7, 2015 AT 11:00 A.M.
CITY HALL, CITY CLERK'S OFFICE,
240 W. HUNTINGTON DRIVE, ARCADIA, CA 91007
0
CITY OF ARCADIA
2014/2015 ANNUAL SLURRY SEAL PROJECT
PROJECT No.: 55331015
CONTRACT
BETWEEN
CITY OF ARCADIA
AND
DOUG MARTIN CONTRACTING CO., INC.
N
(PROJECT NO. 55331015)
R7 CONTRACT FOR THE
CITY OF ARCADIA
THIS CONTRACT is made this-110A day of W14 2015, in the County of Los
Angeles, State of California, by and between the City of Arcadia hereinafter called City, and DOUG
MARTIN CONTRACTING CO., INC., hereinafter called Contractor. The City and the Contractorfor
the considerations stated herein agree as follows:
ARTICLE 1. SCOPE OF WORK. The Contractor shall perform all Work within the time stipulated
the Contract and shall provide all labor, materials, equipment, tools, utility services, and
transportation to complete all of the Work required in strict compliance with the Contract Documents
as specified in Article 5 below for the following Project:
2014/2015 Annual Slurry Seal Project; Project No.: 55331015
The Contractor and its surety shall be liable to the City for any damages arising as a result of the
Contractor's failure to comply with this obligation.
ARTICLE 2. TIME FOR COMPLETION.
2.1 The Work shall be commenced on the date stated in the City's Notice to Proceed. The
Contractor shall complete all Work required by the Contract Documents within 45 calendar
days from the commencement date stated in the Notice to Proceed. By its signature
hereunder, Contractor agrees the time for completion set forth above is adequate and
reasonable to complete the Work.
2.2 Contractor shall coordinate the Work with the other work being performed on the Project, in
accordance with those schedules as may be issued from time to time during the
performance of the Work, and any other scheduling requirements listed in this Contract, so
as not to delay, impede, obstruct, hinder or interfere with the commencement, progress or
completion of the whole or any part of the Work or other work on the Project.
2.3 The Contractor shall participate and cooperate with the City in the development of schedules
and other efforts to achieve timely completion of the Work providing information for the
scheduling of the times and sequence of operations required for its Work ( "Contractor
Schedule ") to meet City's overall master project schedule requirements ( "Master Schedule ").
The Contractor shall continuously monitor the Master Schedule so as to be fully familiar
with the timing, phasing and sequence of operations of the Work and of other work on the
Project, and shall execute the Work in accordance with the requirements of the Master
Schedule including any revisions thereto. The Contractor shall notify the Engineerwithin 48
hours of any slippage in the Contractor Schedule and shall submit a detailed recovery plan
to the Engineer for approval within five (5) calendar days of such notice.
2.4 Should the progress of the Work or of the Project be delayed disrupted, hindered,
obstructed, or interfered with by any fault or neglect or act or failure to act of the Contractor
or any of its officers, agents, servants, employees, subcontractors or suppliers so as to
cause any additional cost, expense, liability or damage to the City, the Engineer or any
consultants retained by the City for the Project, including legal fees and disbursements
incurred by the City, the Engineer, or the consultants retained by the City for the Project,
(whether incurred in defending claims arising from such delay or in seeking reimbursement
and indemnity from the Contractor and its surety hereunder or otherwise) or any damages or
additional costs or expenses for which the City, the Engineer or the consultants retained by
the City for the Project, may or shall become liable, the Contractor and its surety shall and
does hereby agree to compensate the City, the Engineer or the consultants retained by the
Contract - 1
(PROJECT NO. 55331015)
City for the Project„ for and indemnify them against all such costs, expenses, damages and
liability.
1 2.5 The City, in its sole discretion, may direct the Contractor to work overtime and, if so directed,
the Contractor shall work said overtime and, provided that the Contractor is not in default
under any of the terms or provisions of this Contract or of any of the other Contract
Documents, the City will pay the Contractor for such actual additional wages paid, if any, at
the prevailing wage rates plus taxes imposed by law on such additional wages, plus
workers' compensation insurance, liability insurance and levies on such additional wages if
required to be paid by the Contractor.
2.6 If, however, the progress of the Work or of the Project is delayed by any fault or neglect or
act or failure to act of the Contractor or any of its officers, agents, servants, employees,
subcontractors or suppliers, then the Contractor shall, in addition to all of the other
obligations imposed by this Contract upon the Contractor in such case, and at its own cost
and expense, work such overtime as may be necessary to make up for all time lost in the
completion of the Work and of the Project due to such delay. Should the Contractor fail to
make up for the time lost by reason of such delay, the Engineer or City shall have the right
to cause other contractors to work overtime and to take whatever other action it deems
necessary to avoid delay in the completion of the Work and of the Project, and the cost and
expense of such overtime and /or such other action shall be borne solely by the Contractor.
ARTICLE 3. CONTRACT PRICE. The City shall pay to the Contractor as full compensation for
the performance of the Contract, subject to any additions or deductions as provided in the Contract
Documents, and including all applicable taxes and costs, the sum of FIVE HUNDRED SEVENTY-
SIX THOUSAND SEVEN HUNDRED FIVE DOLLARS AND TWENTY CENTS ($576,705.20).
Payment shall be made as set forth in the General Conditions.
ARTICLE 4. PAYMENTS
4.1 The City shall make monthly progress payments following receipt of undisputed and properly
submitted payment requests. Contractor shall be paid a sum equal to ninety -five percent
(95 %) of the value of Work performed up to the last day of the previous month, less the
aggregate of previous payments.
4.2 The Contractor shall, after the full completion of The Work, submit a final payment
application. All prior progress estimates shall be subject to correction in the final estimate
and payment.
4.3 Unless otherwise required by law, the final payment of five percent (5 %) of the value of the
Work, if unencumbered, shall be paid no later than sixty (60) Days after the date of
recordation of the Notice of Completion.
4.4 Acceptance by Contractor of the final payment shall constitute a waiver of all claims against
the City arising from this Contract.
4.5 Payments to the Contractor shall not be construed to be an acceptance of any defective
work or improper materials, or to relieve the Contractor of its obligations under the Contract
Documents.
4.6 The Contractor shall submit with each payment request the Contractor's conditional waiver
of lien for the entire amount covered by such payment request, as well as a valid
unconditional waiver of lien from the Contractor and all subcontractors and materialmen for
all work and materials included in any prior invoices. Waivers of lien shall be in the forms
Contract - 2
(PROJECT NO. 55331015)
prescribed by California Civil Code sections 8132, 8134, 8136, and 8138. Prior to final
payment by the City, the Contractor shall submit a final waiver of lien for the Contractor's
work, together with releases of lien from any subcontractor or materialmen.
ARTICLE S. PAYMENTS WITHHELD AND BACKCHARGES In addition to amounts which the
City may retain under other provisions of the Contract Documents the City may withhold payments
due to Contractor as may be necessary to cover:
a. Stop Notice Claims.
b. Defective work not remedied.
C. Failure of Contractor to make proper payments to its subcontractors or suppliers.
d. Completion of the Contract if there exists a reasonable doubt that the Work can be
completed for balance then unpaid.
e. Damage to another contractor or third party.
Amounts which may be due the City for claims against Contractor.
g. Failure of Contractor to keep the record ( "as- built ") drawings up to date.
h. Failure to provide updates on the construction schedule.
Site clean -up.
Failure of the Contractor to comply with requirements of the Contract Documents.
k. Liquated damages.
Legally permitted penalties.
Upon completion of the Contract, the City will reduce the final Contract amount to reflect costs
charged to the Contractor, backcharges or payments withheld pursuant to the Contract Documents.
ARTICLE 6. CHANGES AND EXTRA WORK
6.1 The City, without invalidating the Contract, may order changes in the Work consisting of
additions, deletions or other revisions, the Contract amount and Contract time being
adjusted accordingly. All such changes in the Work shall be authorized by Change Order, in
the form attached hereto and incorporated herein as Exhibit "A," and shall be performed
under the applicable conditions of the Contract Documents. A Change Order signed by the
Contractor indicates the Contractor's agreement therewith, including any adjustment in the
Contract amount or the Contract time, and the full and final settlement of all costs (direct,
indirect and overhead) related to the Work authorized by the Change Order.
6.2 All claims for additional compensation to the Contractor shall be presented in writing before
the expense is incurred and will be adjusted as provided herein. No work shall be allowed
to lag pending such adjustment, but shall be promptly executed as directed, even if a
dispute arises. No claim will be considered after the work in question has been done unless
a written contract change order has been issued or a timely written notice of claim has been
made by Contractor. Contractor shall not be entitled to claim or bring suit for damages,
whether for loss of profits or otherwise, on account of any decrease or omission of any item
Contract - 3
14 (PROJECT NO. 55331015)
or portion of Work to be done. Whenever any change is made as provided for herein, such
change shall be considered and treated as though originally included in the Contract, and
shall be subject to all terms, conditions and provisions of the original Contract.
6.3 Owner Initiated Change. The Contractor must submit a complete cost proposal, including
any change in the Contract time, within seven (7) Days after receipt of a scope of a
proposed change order, unless the City requests that proposals be submitted in less than
seven (7) Days.
6.4 Contractor Initiated Change. The Contractor must give written notice of a proposed change
order required for compliance with the Contract Documents within seven (7) Days of
discovery of the facts giving rise to the proposed change order.
6.5 Whenever possible, any changes to the Contract amount shall be in a lump sum mutually
agreed to by the Contractor and the City.
6.6 Price quotations from the Contractor shall be accompanied by sufficiently detailed
supporting documentation to permit verification by the City.
6.7 If the Contractor fails to submit the cost proposal within the seven (7) Day period (or as
requested), the City has the right to order the Contractor in writing to commence the work
immediately on a force account basis and/or issue a lump sum change to the contract price
in accordance with the City's estimate of cost. If the change is issued based on the City
estimate, the Contractor will waive its right to dispute the action unless within fifteen (15)
Days following completion of the added /deleted work, the Contractor presents written proof
that the City's estimate was in error.
6.8 Estimates for lump sum quotations and accounting for cost - plus - percentage work shall be
limited to direct expenditures necessitated specifically by the subject extra work, and shall
be segregated as follows:
(a) Labor. The costs of labor will be the actual cost for wages prevailing locally
for each craft or type of worker at the time the extra work is done, plus
employer payments of payroll taxes and insurance, health and welfare,
pension, vacation, apprenticeship funds, and other direct costs resulting from
Federal, State or local laws, as well as assessment or benefits required by
lawful collective bargaining agreements. The use of a labor classification
which would increase the extra work cost will not be permitted unless the
contractor establishes the necessity for such additional costs. Labor costs
for equipment operators and helpers shall be reported only when such costs
are not included in the invoice for equipment rental.
(b) Materials. The cost of materials reported shall be at invoice or lowest current
price at which such materials are locally available in the quantities involved,
plus sales tax, freight and delivery. Materials cost shall be based upon
supplier or manufacturer's invoice. If invoices or other satisfactory evidence
of cost are not furnished within fifteen (15) Days of delivery, then the
Engineer shall determine the materials cost, at its sole discretion.
(c) Tool and Equipment Use. No payment will be made for the use of small
tools, tools which have a replacement value of $1,000 or less. Regardless of
ownership, the rates to be used in determining equipment use costs shall not
exceed listed rates prevailing locally at equipment rental agencies, or
distributors, at the time the work is performed.
Contract - 4
(PROJECT NO. 55331015)
'R! (d) Overhead, Profit and Other Charges. The mark -up for overhead (including
supervision) and profit on work added to the Contract shall be according to
the following:
"Net Cost" is defined as consisting of costs of labor, materials and tools and
equipment only excluding overhead and profit. The costs of applicable insurance
and bond premium will be reimbursed to the Contractor and subcontractors at cost
only, without mark -up.
For Work performed by the Contractor's forces the added cost for overhead and
profit shall not exceed fifteen (15 %) percent of the Net Cost of the Work.
iii. For Work performed by a subcontractor, the added cost for overhead and profit shall
not exceed fifteen (15 %) percent of the Net Cost of the Work to which the Contractor
may add five (5 %) percent of the subcontractor's Net Cost.
iv. For Work performed by a sub - subcontractor the added cost for overhead and profit
shall not exceed fifteen (15 %) percent of the Net Cost for Work to which the
subcontractor and general contractor may each add an additional five (5 %) percent
of the Net Cost of the lower tier subcontractor.
V. No additional markup will be allowed for lower tier subcontractors, and in no case
shall the added cost for overhead and profit payable by City exceed twenty -five
(25 %) percent of the Net Cost as defined herein.
6.9 For added or deducted Work by subcontractors, the Contractor shall furnish to the
City the subcontractor's signed detailed estimate of the cost of labor, material and
equipment, including the subcontractor markup for overhead and profit. The same
requirement shall apply to sub - subcontractors.
6.10 For added or deducted work furnished by a vendor or supplier, the Contractor shall
furnish to the City a detailed estimate or quotation of the cost to the Contractor,
signed by such vendor or supplier.
6.11 Any change in The Work involving both additions and deletions shall indicate a net
total cost, including subcontracts and materials. Allowance for overhead and profit,
as specified herein, shall be applied if the net total cost is an extra; overhead and
profit allowances shall not be applied if the net total cost is a credit. The estimated
cost of deductions shall be based on labor and material prices on the date the
Contract was executed.
6.12 Contractor shall not reserve a right to assert impact costs, extended job site costs,
extended overhead, constructive acceleration and/or actual acceleration beyond
what is stated in the change order for work. No claims shall be allowed for impact,
extended overhead costs, constructive acceleration and/or actual acceleration due to
a multiplicity of changes and /or clarifications. The Contractor may not change or
modify the City's change order form in an attempt to reserve additional rights.
6.13 If the City disagrees with the proposal submitted by Contractor, it will notify the
Contractor and the City will provide its opinion of the appropriate price and /or time
extension. If the Contractor agrees with the City, a change order will be issued by
the City. If no agreement can be reached, the City shall have the right to issue a
unilateral change order setting forth its determination of the reasonable additions or
savings in costs and time attributable to the extra or deleted work. Such
Contract - 5
(PROJECT NO. 55331015)
determination shall become final and binding if the Contractor fails to submit a claim
in writing to the City within fifteen (15) Days of the issuance of the unilateral change
order, disputing the terms of the unilateral change order.
6.14 No dispute, disagreement or failure of the parties to reach agreement on the terms of
the change order shall relieve the Contractor from the obligation to proceed with
performance of the work, including extra work, promptly and expeditiously.
6.15 Any alterations, extensions of time, extra work or any other changes may be made
without securing consent of the Contractor's surety or sureties.
ARTICLE 7. LIQUIDATED DAMAGES. In accordance with Government Code section 53069.85,
it is agreed that the Contractor will pay the City the sum of $1,500.00 for each and every calendar
day of delay beyond the time prescribed in the Contract Documents for finishing the Work, as
Liquidated Damages and not as a penalty or forfeiture. In the event this is not paid, the Contractor
agrees the City may deduct that amount from any money due or that may become due the
Contractor under the Contract. This Article does not exclude recovery of other damages specified in
the Contract Documents.
ARTICLE 8. COMPONENT PARTS OF THE CONTRACT. The "Contract Documents" include the
following:
Notice Inviting Bids
Instructions to Bidders
Contractor's Bid Forms
Contractor's Certificate Regarding Workers' Compensation
Bid Bond
Designation of Subcontractors
Information Required of Bidders
Non - Collusion Declaration form
Iran Contracting Act Certification form
Public Works Contractor Registration Certification form
Contract
Performance Bond
Payment (Labor and Materials) Bond
General Conditions
Special Provisions (or Special Conditions)
Technical Specifications
California Building Codes as defined in the General Conditions
Addenda
Plans and Contract Drawings
Approved and fully executed change orders
Any other documents contained in or incorporated into the Contract
The Contactor shall complete the Work in strict accordance with all of the Contract Documents
All of the Contract Documents are intended to be complementary. Work required by one of the
Contract Documents and not by others shall be done as if required by all. This Contract shall
supersede any prior agreement of the parties.
ARTICLE 9. PROVISIONS REQUIRED BY LAW. Each and every provision of law required to be
included in these Contract Documents shall be deemed to be included in these Contract
Documents. The Contractor shall comply with all requirements of applicable federal, state and local
Contract - 6
(PROJECT NO. 55331015)
laws, rules and regulations, including, but not limited to, the provisions of the California Labor Code
and California Public Contract Code which are applicable to this Project.
ARTICLE 10. INDEMNIFICATION.
10.1 To the fullest extent permitted by law, the Contractor shall defend, indemnify and hold
harmless the City, its respective officials, officers, agents, employees, and representatives
( "Indemnitees ") from any and all claims, demands, causes of action, costs, expenses,
liabilities, losses, damages (including without limitation the payment of all consequential
damages and attorneys fees and other related costs and expenses) or injuries, in law or
equity, regardless of whether the allegations are false, fraudulent, or groundless, to tangible
property or persons (including wrongful death, accidents or injuries arising from the alleged
failure to inspect or to maintain traffic controllers or traffic signals, injuries or damages
occurring during the transport of products or in rendering services under the Contract
Documents, such as automobile accidents, trip /slip and fall accidents and third party
assaults) arising out of or resulting from the performance of the Work or this Contract
(including claims made by subcontractors for nonpayment), to the extent that the acts,
omissions or willful misconduct are attributable to the Contractor or anyone employed
directly or indirectly by any of them. Contractor shall defend, at Contractor's own cost,
expense and risk, with legal counsel of Indemnitee's choosing, any and all such aforesaid
suits, actions or other legal proceedings of every kind that may be brought or instituted
against the City, its respective officials, officers, agents, employees and representatives. To
the extent of its liability, Contractor shall pay and satisfy any judgment, award or decree that
may be rendered against the City and its respective officials, officers, agents, employees,
and representatives, in any such suit, action or other legal proceeding. Contractor shall
reimburse the City and its respective officials, officers, agents, employees, and
representatives for any and all legal expenses and costs incurred by each of them in
connection therewith or in enforcing the indemnity herein provided. The only limitations on
this provision shall be those imposed by Civil Code section 2782.
10.2 The duty to defend and to hold harmless, as set forth above, shall include the duty to defend
as established by Section 2778 of the California Civil Code, and the duty to defend shall
arise upon the making of any claim or demand against the City, its respective officials,
officers, agents, employees and representatives, notwithstanding that no adjudication of the
underlying facts has occurred, and whether or not Contractor has been named in the claim
or lawsuit.
10.3 Nothing contained in the preceding sections shall be deemed to obligate the Contractor to
indemnify the City or any of the other Indemnitees, against liability for damages or any other
loss, damage or expense sustained, suffered or incurred on account of death or bodily injury
to active persons or injury to property caused by the sole negligence orwillful misconduct of
the City or any of the other Indemnitees set forth above. Therefore, if it is determined by
legal. proceedings or agreement, that the Contractor has no direct contributory or incidental
negligence or other obligation to the City or the other Indemnitees, and the Contractor is in
no way a proper party to a particular claim, then the Contractor shall not be obligated to hold
the City or any Indemnitees harmless with respect to said claim. However, until such
determination is made by legal proceedings or agreement, or if the Contractor is found to
have any degree of direct or contributory negligence or if it is determined that the Contractor
is in any way or to any degree a proper party to said claim, then the Contractor's obligations
under all of the terms and provisions of the preceding section shall remain in full force and
effect.
10.4 Nothing in this provision, or elsewhere in the Contract Documents, shall be deemed to
relieve the Contractor of its duty to defend the City or any Indemnitee, as specified under
Contract - 7
(PROJECT NO. 55331015)
this Article, pending a determination of the respective liabilities of the City or any Indemnitee,
by legal proceeding or agreement.
14.5 In furtherance to, but not in limitation of the indemnity provisions in this Contract, Contractor
hereby expressly and specifically agrees that its obligation to indemnify, defend and hold
harmless as provided in this Contract shall not in any way be affected or diminished by any
statutory or constitutional immunity it enjoys from suits by its own employees or from
limitations of liability or recovery under workers' compensation laws.
ARTICLE 11. PREVAILING WAGES. Contractor shall be required to pay the prevailing rate of
wages in accordance with the Labor Code which such rates shall be made available at the Public
Works Services Department or may be obtained online at.http//www.dir.ca.qov/dIs and which must
be posted at the job site.
IN WITNESS WHEREOF, this Contract has been duly executed by the above -named parties, on
the day and year above written.
CITY OF ARCADIA DOUG MARTIN CONTRACTING CO., INC.
By: ' By: i )11111
Dominic azzaretto . Name
City Manager D. oug
Title
Attest: Attest: 9
C
By: JAN kltk By:
it C rk f Name
Dixie Martin, Secretary /Treasurer
Title
Approved as to form:
Stephen P. Deitsch
City Attorney
1 Attestation of Contractor's signature must be obtained when required b the by-laws, articles of incorporation
9 q Y Y � P
or other laws, rules or regulations applicable to Contractor's business entity.
Contract - 8
1100-80
2q 71
- This page is part of your document- DO NOT DISCARD -
OfL3 4 20161401333
enftl **
llll I IIIIIIIIIIIIIIIIIIIIIIIIIIIII P28 :
�J11:1` +
Recorded/Filed in Official Records
}k /-4 Recorder's Office, Los Angeles County,
California
C4-4; RN�r 11/09/16 AT 10:37AM
FEES: 0.00
TAXES: 0.00
OTHER: 0.00
PAID: 0.00
III 11 II I 11 11 11111 111
LEADSHEET
I I 111 11 1111 I 111 11
201611092880047
00012896860
III II II III II ����
007928488
SEQ:
02
DAR - Mail (Intake)
I II Nl 1 101 I 1 II III
III III IIII II 111111 I III III IllIllIllIllIll III
- THIS FORM IS NOT TO BE DUPLICATED -
E485912
RECORDING REQUESTED RY
Document Number:12896860
CITY OF ARCADIA 1IIII II II II I Iill I I II If III
AND WHEN RECORDED MAIL TO
NAME TOM TAIT Batch Number:7928488
PUBLIC WORKS SERVICES DIRECTOR II III I IIIII III III III II II
CITY OF ARCADIA
STREET 240 WEST HUNTINGTON DR
PO BOX 60021
CITY ARCADIA, CA 91066-6021
STATE
ZIP
SPACE ABOVE THIS LINE FOR RECORDER'S USE
NOTICE OF COMPLETION
Notice pursuant to Civil Code Section 3093, must be filed within 10 days after completion. (See reverse side for complete requirements.)
Notice is hereby given that:
1. The undersigned is owner or corporate officer of the owner of the interest or estate stated below in the property hereinafter described:
2. The full name of the owner is CITY OF ARCADIA
3. The full address of the owner is 240 WEST HUNTINGTON DRIVE,ARCADIA CALIFORNIA 91007
4. The nature of the interest or estate of the owner is: In fee.
(if other than Fee,strike"In fee"an insert, for example, "purchaser under contract of purchase,"or"Lessee")
5. The full names and full addresses of all persons, if any,who hold title with the undersigned as joint tenants or as tenants in
common are:
NAMES ADDRESSES
6. The full names and full addresses of the predecessors in interest of the undersigned, if the property was transferred subsequent
to the commencement of the work or improvements herein referred to:
NAMES ADDRESSES
7. A work of improvement on the property hereinafter described was completed on OCTOBER 4, 2016 . The work done was:
2015/2016 ANNUAL SLURRY SEAL PROJECT/PROJECT NO. 55331016
8. The names of the contractor, if any,for such work of improvement was AMERICAN ASPHALT SOUTH, INC.
JUNE 15,2016
(If no contractor for work of improvement as a whole,insert"None") (Date of Contract)
9. The property on which said work of improvement was completed is in the City of ARCADIA.
County of LOS ANGELES, State of CA,and is described as follows:VARIOUS LOCATIONS WITHIN THE CITY OF ARCADIA
COUNTY OF LOS ANGELES, STATE OF CALIFORNIA .
10. The street address-of said property is None
(If no street address has been officially assigned,insert"None".)
Dated: OCTOBER 5, 2016 '
Signa u wner or corporat of Owner named in paragraph 2,or his agent
DOMINIC LAZZARETTO, CITY MANAGER
VERIFICATION
I,the undersigned, say: I am the Public Works Services Director,the declarant of the foregoing Notice of Completion;
(President of,Manager of,Partner of,Owner of,etc.)
I have read said Notice of Completion and know the contents thereof;the same is true to my knowledge, I declare under penalty of
perjury that the foregoing is true and correct.
Executed on OCTOBER 5, 2016 ,ARCADI ALIFOR
(Per nal signature f the individual who is swearing that the contents of the Notice of Completion are true)
TOM TAIT, PUBLIC WORKS SERVICES DIRECTOR
DO NOT RECORD
REQUIREMENT AS TO NOTICE OF COMPLETION
Notice of completion must be filed for record WITHIN 10 DAYS after the completion of the work of
improvement (to be computed exclusive of the day of completion) as provided in Civil Code Section
3093.
The "owner" who must file for record a notice of completion of a building or other work of
improvement means the owner (or his successor in-interest at the date the notice is filed) on whose
behalf the work was done, though his ownership is less than the fee title. For example, if A is the owner
in fee, and B, lessee under a lease, causes a building to be constructed, then B, or whoever has
succeeded to his interest at the date the notice is filed, must file the notice.
If the ownership is in two or more persons as joint tenants or tenants in common, the notice may be
signed by any one of the co-owners (in fact, the foregoing form is designed for giving of the notice by
only one co-tenant), but the names and addresses of the other co-owners must be stated in paragraph 5
of the form.
Note that any Notice of Completion signed by a successor in interest shall recite the names and
addresses of his transferor or transferors.
In paragraphs 3, 5 and 6, the full address called for should include street number, city, county and
state.
As to paragraphs 7 and 8, this form should be used only where the notice of completion covers the
work of improvement as a whole. If the notice is to be given only of completion of a particular contract,
where the work of improvement is made pursuant to two or more original contracts, then this form must
be modified as follows: (1) Strike the works "A work of improvement" from paragraph 7 and insert a
general statement of the kind of work done or materials furnished pursuant to such contract (e.g., "The
foundation for the improvements"); (2) Insert the name of the contractor under the particular contract in
paragraph 8.
In paragraph 8 of the notice, insert the name of the contractor for the work of improvement as a
whole. No contractor's name need be given if there'is no general contractor, e.g. on so-called "owner-
builder jobs."
In paragraph 9, insert the full, legal description, not merely a street address or tax description.
Refer to deed or policy of title insurance. If the space provided for description is not sufficient, a rider
may be attached.
In paragraph 10, show the street address, if any, assigned to the property by any competent public
or governmental authority.