Loading...
HomeMy WebLinkAboutItem 10i - Downtown Lighting Improvement Project STAFF REPORT DEVELOPMENT SERVICES DEPARTMENT DATE: August 19, 2025 TO: Honorable Mayor and City Council FROM: Jason Kruckeberg, Assistant City Manager/Development Services Director Kevin Merrill, City Engineer By: Simon Vuong, Economic Development Manager SUBJECT: CONTRACT WITH CALIFORNIA PROFESSIONAL ENGINEERING, INC. FOR THE DOWNTOWN LIGHTING IMPROVEMENT PROJECT IN THE AMOUNT OF $247,000, INCLUDING A 10% CONTINGENCY, UTILIZING AMERICAN RESCUE PLAN ACT (“ARPA”) FUNDS CEQA: Exempt Recommendation: Approve SUMMARY The Downtown Lighting Improvement Project was added to the Fiscal Year 2023- 2024 Capital Improvement Program (“CIP”) to improve the Huntington Drive corridor within Downtown Arcadia, between Santa Clara Street and Fifth Avenue. The Project includes wrapped lighting and uplighting on a total of 67 trees in the Downtown area. The original bid was advertised and opened on March 6, 2025, but only two (2) bids were received, and both were significantly higher than the budget. The project was re-advertised and bids were opened on June 19, 2025, with California Professional Engineering, Inc., as the lowest responsible bidder. It is recommended that the City Council find the project categorically exempt under the California Environmental Quality Act (“CEQA”); and authorize the City Manager to enter into a contract with California Professional Engineering, Inc. for the Downtown Lighting Improvement Project in the amount of $247,000, including a 10% contingency, utilizing American Rescue Plan Act (“ARPA”) funds. Downtown Lighting Improvement Project August 19, 2025 Page 2 of 4 BACKGROUND The Downtown Lighting Project was included in the Fiscal Year 2023-24 CIP to enhance the Downtown. The Project includes replacing existing uplights, tree- mounted power boxes, and electrical conduit for palm trees in Downtown Arcadia, which were originally installed in the 1990's as part of the Downtown 2000 Beautification Project, and have reached the end of their lifecycle. New color uplighting and white wrapped lights were proposed to replace the existing lighting, as well as new controller systems and electrical upgrades to update the Huntington Drive corridor . A Professional Services Agreement (“PSA”) was entered into between the City and on- call engineering consultant, Kreuzer Consulting Group (“KCG”), on April 14, 2024. The PSA was drafted to develop and produce base plans, lighting design and imagery, electrical design and lighting plans, and banner pole design and calculations. Design plans were completed and finalized in January 2025. The original bid was advertised and opened on March 6, 2025, but only two (2) bids were received, and both were significantly higher than the budget. The City Council rejected these bids at the meeting on April 15, 2025, and directed staff to re-bid the project with changes. The revised bid documents included plans to reduce costs and modifications that would allow additional bidders to qualify to bid. DISCUSSION A Notice Inviting Bids—with the revised criteria—was published on May 22, 2025, per the City’s purchasing policies. On June 19, 2025, the City received six (6) bids, summarized below: BIDDER AMOUNT California Professional Engineering, Inc. $247,000 Select Electric, Inc. $255,303 MSL Electric Inc. $276,000 Belco Elecnor $277,600 Servitek Electric, Inc. $607,504 Crosstown Electrical & Data, Inc. $655,570 Downtown Lighting Improvement Project August 19, 2025 Page 3 of 4 After reviewing the bid documents, California Professional Engineering, Inc., was determined to be the lowest responsible bidder. California Professional Engineering has performed work with favorable results on several City projects, including, most recently, traffic signal improvements at five intersections along Santa Anita Avenue. Two (2) bids are well above the City’s budget, with the remaining four (4) within 10% - 24% of the project’s original estimate ($225,000). The increase in project costs is primarily due to significant increases in labor and material costs over the last several years. In the approximately three-years since the project was originally envisioned, the estimate of the project’s cost has been eclipsed by inflation, high construction costs in all project types and trades, and a more challenging economic environment. ENVIRONMENTAL ANALYSIS This project is categorically exempt pursuant to the California Environmental Quality Act (“CEQA”) under Section 15301 (Existing Facilities), Section 15302 (Replacement or Reconstruction), and Section 15303 (New Construction or Conversion of Small Structures), as the project involves the replacement of existing facilities by replacing existing uplights, power boxes, and electrical conduit related to the lighting system, and installation of new light fixtures, with no expansion of use. FISCAL IMPACT The Downtown Lighting Improvement Project was included in the FY 2023-2024 CIP, with a budget of $225,000. The funding source for this Project was ARPA funds that had been allocated as part of economic development and community enhancement efforts. California Professional Engineering, Inc. was the lowest responsible bidder with a bid in the amount of $247,000. Including the requested 10% contingency results in a total potential budget of $271,700. The difference in the low bid amount with contingency and the original project budget of $225,000, is $46,700. As part of the allocation of ARPA funds, the City had previously allocated two different installments of funds to the Homeless Diversion Program, in the amounts of $250,000 and $203,600. To date, the Recreation and Community Services Department has expended approximately $70,000 of the original $250,000. Because there are other funding sources available for the Homeless Diversion Program, and the existing funding is ample for the Downtown Lighting Improvement Project August 19, 2025 Page 4 of 4 program, it is recommended that the City Council redirect $46,700 from the Homeless Diversion Program to this Project. This action will ensure the Project is fully funded with ARPA funds; no General Fund dollars are proposed for this work. RECOMMENDATION It is recommended that the City Council determine this project categorically exempt under the California Environmental Quality Act (“CEQA”); and authorize and direct the City Manager to enter into a contract with California Professional Engineering, Inc. for the Downtown Lighting Improvement Project in the amount of $247,000, including a 10% contingency, utilizing American Rescue Plan Act (“ARPA ”) funds. Attachment No. 1: Proposed Contract Attachment No. 2: Map of Project Area CONTRACT This CONTRACT, No. ________ is made and entered into this ____ day of August, 2025, by and between City of Arcadia, sometimes hereinafter called “City,” and California Professional Engineering, Inc., sometimes hereinafter called “Contractor.” WITNESSETH: That the parties hereto have mutually covenanted and agreed, and by these presents do covenant and agree with each other as follows: a. SCOPE OF WORK. The Contractor shall perform all Work within the time stipulated in the Contract, and shall provide all labor, materials, equipment, tools, utility services, and transportation to complete all of the Work required in strict compliance with the Contract Documents as specified in Article 5, below, for the following Project: DOWNTOWN LIGHTING IMPROVEMENT PROJECT The Contractor and its surety shall be liable to the City for any damages arising as a result of the Contractor’s failure to comply with this obligation. b. TIME FOR COMPLETION. Time is of the essence in the performance of the Work. The Work shall be commenced on the date stated in the City’s Notice to Proceed. The Contractor shall complete all Work required by the Contract Documents within 130 calendar days from the commencement date stated in the Notice to Proceed. By its signature hereunder, Contractor agrees the time for completion set forth above is adequate and reasonable to complete the Work. c. CONTRACT PRICE. The City shall pay to the Contractor as full compensation for the performance of the Contract, subject to any additions or deductions as provided in the Contract Documents, and including all applicable taxes and costs, the sum of TWO HUNDRED SEVENTY- ONE THOUSAND AND SEVEN HUNDRED DOLLARS ($271,000.00). Payment shall be made as set forth in the General Conditions. d. LIQUIDATED DAMAGES. In accordance with Government Code section 53069.85, it is agreed that the Contractor will pay the City the sum set forth in Section 00 73 13, Article 1.11 for each and every calendar day of delay beyond the time prescribed in the Contract Documents for finishing the Work, as Liquidated Damages and not as a penalty or forfeiture. In the event this is not paid, the Contractor agrees the City may deduct that amount from any money due or that may become due the Contractor under the Contract. This Article does not exclude recovery of other damages specified in the Contract Documents. e. COMPONENT PARTS OF THE CONTRACT. The “Contract Documents” include the following: Notice Inviting Bids Instructions to Bidders Bid Form Bid Bond Designation of Subcontractors Information Required of Bidders Non-Collusion Declaration Form Iran Contracting Act Certification Public Works Contractor Registration Certification Attachment No. 1 Performance Bond Payment (Labor and Materials) Bond General Conditions Special Conditions Technical Specifications Addenda Plans and Drawings Standard Specifications for Public Works Construction “Greenbook”, latest edition, Except Sections 1-9 Applicable Local Agency Standards and Specifications, as last revised Approved and fully executed change orders Any other documents contained in or incorporated into the Contract The Contractor shall complete the Work in strict accordance with all of the Contract Documents. All of the Contract Documents are intended to be complementary. Work required by one of the Contract Documents and not by others shall be done as if required by all. This Contract shall supersede any prior agreement of the parties. f. PROVISIONS REQUIRED BY LAW AND CONTRACTOR COMPLIANCE. Each and every provision of law required to be included in these Contract Documents shall be deemed to be included in these Contract Documents. The Contractor shall comply with all requirements of applicable federal, state and local laws, rules and regulations, including, but not limited to, the provisions of the California Labor Code and California Public Contract Code which are applicable to this Work. g. INDEMNIFICATION. Contractor shall provide indemnification and defense as set forth in the General Conditions. h. PREVAILING WAGES. Contractor shall be required to pay the prevailing rate of wages in accordance with the Labor Code which such rates shall be made available at the City’s Administrative Office or may be obtained online at http://www.dir.ca.gov and which must be posted at the job site. [REMAINDER OF PAGE LEFT INTENTIONALLY BLANK] IN WITNESS WHEREOF, this Contract has been duly executed by the above-named parties, on the day and year above written. CITY OF ARCADIA CALIFORNIA PROFESSIONAL ENGINEERGING, INC. By: _____ By: Dominic Lazzaretto City Manager Its: Printed Name: ATTEST: By: _____________________________ By: Its: _____________________________ City Clerk Printed Name:_______________________ APPROVED AS TO FORM: By: City Attorney (CONTRACTOR’S SIGNATURE MUST BE NOTARIZED AND CORPORATE SEAL AFFIXED, IF APPLICABLE) END OF CONTRACT Notary Acknowledgment A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA COUNTY OF ______________ On , 20___, before me, _______________________________, Notary Public, personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT  Individual  Corporate Officer Title(s) Title or Type of Document  Partner(s)  Limited  General Number of Pages  Attorney-In-Fact  Trustee(s)  Guardian/Conservator Date of Document  Other: Signer is representing: Name Of Person(s) Or Entity(ies) Signer(s) Other Than Named Above PAYMENT BOND (LABOR AND MATERIALS) KNOW ALL MEN BY THESE PRESENTS That WHEREAS, the City of Arcadia (hereinafter designated as the “City”), by action taken or a resolution passed August ____, 2025, has awarded to CALIFORNIA PROFESSIONAL ENGINEERING, INC., hereinafter designated as the “Principal,” a contract for the work described as follows: Contract No.____________ (the “Project”); and WHEREAS, said Principal is required to furnish a bond in connection with said contract; providing that if said Principal or any of its Subcontractors shall fail to pay for any materials, provisions, provender, equipment, or other supplies used in, upon, for or about the performance of the work contracted to be done, or for any work or labor done thereon of any kind, or for amounts due under the Unemployment Insurance Code or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of said Principal and its Subcontractors with respect to such work or labor the Surety on this bond will pay for the same to the extent hereinafter set forth. NOW THEREFORE, we, the Principal and __________________________ as Surety, are held and firmly bound unto the City in the penal sum of ______________ Dollars ($___________) lawful money of the United States of America, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if said Principal, his or its subcontractors, heirs, executors, administrators, successors or assigns, shall fail to pay any of the persons named in Civil Code Section 9100, fail to pay for any materials, provisions or other supplies, used in, upon, for or about the performance of the work contracted to be done, or for any work or labor thereon of any kind, or amounts due under the Unemployment Insurance Code with respect to work or labor performed under the contract, or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department or Franchise Tax Board from the wages of employees of the contractor and his subcontractors pursuant to Revenue and Taxation Code Section 18663, with respect to such work and labor the Surety or Sureties will pay for the same, in an amount not exceeding the sum herein above specified, and also, in case suit is brought upon this bond, all litigation expenses incurred by the City in such suit, including reasonable attorneys’ fees, court costs, expert witness fees and investigation expenses. This bond shall inure to the benefit of any of the persons named in Civil Code Section 9100 so as to give a right of action to such persons or their assigns in any suit brought upon this bond. It is further stipulated and agreed that the Surety on this bond shall not be exonerated or released from the obligation of this bond by any change, extension of time for performance, addition, alteration or modification in, to, or of any contract, plans, specifications, or agreement pertaining or relating to any scheme or work of improvement herein above described, or pertaining or relating to the furnishing of labor, materials, or equipment therefore, nor by any change or modification of any terms of payment or extension of the time for any payment pertaining or relating to any scheme or work of improvement herein above described, nor by any rescission or attempted rescission or attempted rescission of the contract, agreement or bond, nor by any conditions precedent or subsequent in the bond attempting to limit the right of recovery of claimants otherwise entitled to recover under any such contract or agreement or under the bond, nor by any fraud practiced by any person other than the claimant seeking to recover on the bond and that this bond be construed most strongly against the Surety and in favor of all persons for whose benefit such bond is given, and under no circumstances shall Surety be released from liability to those for whose benefit such bond has been given, by reason of any breach of contract between the owner or City and original contractor or on the part of any obligee named in such bond, but the sole conditions of recovery shall be that claimant is a person described in Civil Code Section 9100, and has not been paid the full amount of his claim and that Surety does hereby waive notice of any such change, extension of time, addition, alteration or modification herein mentioned, including but not limited to the provisions of sections 2819 and 2845 of the California Civil Code. By their signatures hereunder, Surety and Principal hereby confirm under penalty of perjury that surety is an admitted surety insurer authorized to do business in the State of California. IN WITNESS WHEREOF, we have hereunto set our hands and seals this _______ day of ______________, 20__. (Corporate Seal) Contractor/ Principal By Title (Corporate Seal) Surety By Attorney-in-Fact (Attach Attorney-in-Fact Certificate) Title Notary Acknowledgment A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA COUNTY OF ______________ On , 20___, before me, _______________________________, Notary Public, personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT  Individual  Corporate Officer Title(s) Title or Type of Document  Partner(s)  Limited  General Number of Pages  Attorney-In-Fact  Trustee(s)  Guardian/Conservator Date of Document  Other: Signer is representing: Name Of Person(s) Or Entity(ies) Signer(s) Other Than Named Above NOTE: This acknowledgment is to be completed for Contractor/Principal. Notary Acknowledgment A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA COUNTY OF ______________ On , 20___, before me, _______________________________, Notary Public, personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT  Individual  Corporate Officer Title(s) Title or Type of Document  Partner(s)  Limited  General Number of Pages  Attorney-In-Fact  Trustee(s)  Guardian/Conservator Date of Document  Other: Signer is representing: Name Of Person(s) Or Entity(ies) Signer(s) Other Than Named Above NOTE: This acknowledgment is to be completed for the Attorney-in-Fact. The Power-of-Attorney to local representatives of the bonding company must also be attached. END OF PAYMENT BOND PERFORMANCE BOND KNOW ALL PERSONS BY THESE PRESENTS: THAT WHEREAS, the City of Arcadia, (hereinafter referred to as “City”) has awarded to CALIFORNIA PROFESSIONAL ENGINEERING, INC., (hereinafter referred to as the “Contractor”) an agreement for Contract No._________, (hereinafter referred to as the “Project”). WHEREAS, the work to be performed by the Contractor is more particularly set forth in the Contract Documents for the Project dated ________________, (hereinafter referred to as “Contract Documents”), the terms and conditions of which are expressly incorporated herein by reference; and WHEREAS, the Contractor is required by said Contract Documents to perform the terms thereof and to furnish a bond for the faithful performance of said Contract Documents. NOW, THEREFORE, we, ______________________, the undersigned Contractor and ________________________________________________ as Surety, a corporation organized and duly authorized to transact business under the laws of the State of California, are held and firmly bound unto the City in the sum of ___________________________ DOLLARS, ($____________), said sum being not less than one hundred percent (100%) of the total amount of the Contract, for which amount well and truly to be made, we bind ourselves, our heirs, executors and administrators, successors and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, that, if the Contractor, his or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and agreements in the Contract Documents and any alteration thereof made as therein provided, on its part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their intent and meaning; and shall faithfully fulfill all obligations including the one (1) year guarantee of all materials and workmanship; and shall indemnify and save harmless the City, its officials, officers, employees, and authorized volunteers, as stipulated in said Contract Documents, then this obligation shall become null and void; otherwise it shall be and remain in full force and effect. As a part of the obligation secured hereby and in addition to the face amount specified therefore, there shall be included costs and reasonable expenses and fees including reasonable attorney’s fees, incurred by City in enforcing such obligation. As a condition precedent to the satisfactory completion of the Contract Documents, unless otherwise provided for in the Contract Documents, the above obligation shall hold good for a period of one (1) year after the acceptance of the work by City, during which time if Contractor shall fail to make full, complete, and satisfactory repair and replacements and totally protect the City from loss or damage resulting from or caused by defective materials or faulty workmanship. The obligations of Surety hereunder shall continue so long as any obligation of Contractor remains. Nothing herein shall limit the City’s rights or the Contractor or Surety’s obligations under the Contract, law or equity, including, but not limited to, California Code of Civil Procedure Section 337.15. Whenever Contractor shall be, and is declared by the City to be, in default under the Contract Documents, the Surety shall remedy the default pursuant to the Contract Documents, or shall promptly, at the City’s option: i. Take over and complete the Project in accordance with all terms and conditions in the Contract Documents; or ii. Obtain a bid or bids for completing the Project in accordance with all terms and conditions in the Contract Documents and upon determination by Surety of the lowest responsive and responsible bidder, arrange for a Contract between such bidder, the Surety and the City, and make available as work progresses sufficient funds to pay the cost of completion of the Project, less the balance of the contract price, including other costs and damages for which Surety may be liable. The term “balance of the contract price” as used in this paragraph shall mean the total amount payable to Contractor by the City under the Contract and any modification thereto, less any amount previously paid by the City to the Contractor and any other set offs pursuant to the Contract Documents. iii. Permit the City to complete the Project in any manner consistent with California law and make available as work progresses sufficient funds to pay the cost of completion of the Project, less the balance of the contract price, including other costs and damages for which Surety may be liable. The term “balance of the contract price” as used in this paragraph shall mean the total amount payable to Contractor by the City under the Contract and any modification thereto, less any amount previously paid by the City to the Contractor and any other set offs pursuant to the Contract Documents. Surety expressly agrees that the City may reject any contractor or subcontractor which may be proposed by Surety in fulfillment of its obligations in the event of default by the Contractor. Surety shall not utilize Contractor in completing the Project nor shall Surety accept a bid from Contractor for completion of the Project if the City, when declaring the Contractor in default, notifies Surety of the City’s objection to Contractor’s further participation in the completion of the Project. The Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Contract Documents or to the Project to be performed thereunder shall in any way affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Contract Documents or to the Project. By their signatures hereunder, Surety and Contractor hereby confirm under penalty of perjury that surety is an admitted surety insurer authorized to do business in the State of California. [REMAINDER OF PAGE LEFT INTENTIONALLY BLANK] IN WITNESS WHEREOF, we have hereunto set our hands and seals this _______ day of ______________, 20___. (Corporate Seal) Contractor/ Principal By Title (Corporate Seal) Surety By Attorney-in-Fact (Attach Attorney-in-Fact Certificate) Title The rate of premium on this bond is ____________ per thousand. The total amount of premium charges is $_______________________________. (The above must be filled in by corporate attorney.) THIS IS A REQUIRED FORM Any claims under this bond may be addressed to: (Name and Address of Surety) ___________________________________________ ___________________________________________ ___________________________________________ (Name and Address of Agent or ___________________________________________ Representative for service of ___________________________________________ process in California, if different ___________________________________________ from above) (Telephone number of Surety ___________________________________________ and Agent or Representative for service of process in California) NOTE: A copy of the Power-of-Attorney to local representatives of the bonding company must be attached hereto in addition to appropriate Notarial Acknowledgements of Execution by both Contractor and Surety. Notary Acknowledgment A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA COUNTY OF ______________ On , 20___, before me, _______________________________, Notary Public, personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT  Individual  Corporate Officer Title(s) Title or Type of Document  Partner(s)  Limited  General Number of Pages  Attorney-In-Fact  Trustee(s)  Guardian/Conservator Date of Document  Other: Signer is representing: Name Of Person(s) Or Entity(ies) Signer(s) Other Than Named Above NOTE: This acknowledgment is to be completed for Contractor/Principal. Notary Acknowledgment A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA COUNTY OF ______________ On , 20___, before me, _______________________________, Notary Public, personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT  Individual  Corporate Officer Title(s) Title or Type of Document  Partner(s)  Limited  General Number of Pages  Attorney-In-Fact  Trustee(s)  Guardian/Conservator Date of Document  Other: Signer is representing: Name Of Person(s) Or Entity(ies) Signer(s) Other Than Named Above NOTE: This acknowledgment is to be completed for the Attorney-in-Fact. The Power-of Attorney to local representatives of the bonding company must also be attached. END OF PERFORMANCE BOND Insert W9 form on PDF copy.